Advertisement for Electronic Bids For Construction at Waupaca Municipal Airport Waupaca, Wisconsin Project no. AIP 3-55-0091-13 / PCZ1004 THIS PROJECT WILL BE ELECTRONICALLY BID. Paper bids will NOT be accepted or allowed. Sealed ELECTRONIC proposals for the work described herein will be received until 2:00 p.m., local time, Thursday, March 6, 2025, by the Wisconsin Department of Transportation, Bureau of Aeronautics, on behalf of the Secretary, authorized agent for City of Waupaca, in accordance with Wis. Stat. §114.32(3). Bids will be unsealed (electronically opened) as provided above and will be publicly read. The bid opening will be broadcast live via Teams. The correct meeting and call-in information for the bid opening is: Microsoft Teams meeting Join on your computer, mobile app or room device Meeting ID: 273 385 39796 Passcode: tLjwfv Or Dial in by phone (audio only) +1 608-571-2209 United States, Madison Phone Conference ID: 186 780 348# Bid results will be posted as soon as practicable after the close of bids. The bid results will be posted to the Bureau of Aeronautics’ website and BidExpress.com here: https://wisconsindot.gov/Pages/doing- bus/aeronautics/airports/arpt- bidinfo.aspx https://bidexpress.com/businesses/51 671/home Electronic Bid submittal: Bids must be submitted via the bidexpress.com bidding service. No paper bids will be accepted. Bids will not be accepted past the established deadline for the close of bids. Description of work: Grading, Storm Sewer, Base Course, Asphalt Pavement, Erosion Control, Landscaping, Pavement Marking, Gate and Electrical Work. Estimate of major quantities: Common Excavation 2,000 CY; Aggregate Base Course 2,325 Ton; Storm Sewer Reinforced Concrete 216 LF; Storm Water Inlet 2 Each; HMA Pavement 375 Tons; Landscaping 4,850 SY; Traffic Control 1 LS; Electrically Operated Sliding Gate 1 LS DBE Goal: 3.9% Contract Completion Time: 35 Working Days (See Special Provisions) Proposals: Proposal forms are included with the plans and specifications, and are subject to the provisions of Wis. Stat.§66.0901(7). Plans and specifications: Plans and specifications can be obtained free of charge and at the following site: https://bidexpress.com/businesses/5167 1/home Proposal ELECTRONIC Submittal: This contract is being electronically bid . The bid template within BidExpress.com platform established for the project includes all elements required to be submitted with the contract. Required fields are established within the template. Automatic checking of the bid proposal will identify if any required fields are missing and alert the bidder to complete the missing information prior to final submission. Submission of an incomplete bid will result in the bid not being opened, and/or rejected as non-responsive. Plan holder registration required: Plans and specifications are available to anyone after completing a simple registration. There is NO cost to obtain a registration. Registration is required to be recorded asa plan holder. Registered plan holders will be notified of important project information such as issuance of addendums or other critical information. Only the prime or general contractor selecting to submit a bid is required to obtain additional Digital ID credentials. Please contact BidExpress support for registration assistance at, Phone: (888)-352-2439 / Email: support@bidexpress.com. Bidder Digital ID Required: Firms who select to submit a bid MUST also obtain a free digital ID in addition to registering. Obtaining a digital ID is relatively quick, however it may take a couple of days to complete the process. Please request and obtain registration and digital ID’s as early as possible to not jeopardize your ability to submit a bid. There is NO cost to obtain a digital ID. Please contact BidExpress support for Digital ID assistance at, Phone: (888)-352-2439 / Email: support@bidexpress.com. Proposal guaranty: A bid security in the amount of 5% of the total amount of the bid is required for the contract. Each proposal must be accompanied by a bid bond, certificate of annual bid bond, a certified check, bank's draft, bank's check, or postal money order made payable to the Wisconsin Department of Transportation Secretary for 5% of the total amount bid. The electronic template will allow the following options for meeting the proposal guaranty. E-Verify bid bond (Surety2000 &SurePath), uploading a copy of the bid bond or certificate of annual bid bond, certified check, bank draft, or money order. Any bid security, other than a E-verified bond or certificate of annual bid bond is provided, the department will require that the apparent two lowest bidders to mail or hand-deliver the original bond, certified check, bank draft, or money order to the Bureau of Aeronautics by close of business two business days following the close of bids and must be received by the Bureau of Aeronautics no later than 5 days from the posting of the bid results. Qualification of bidders: IMPORTANT: A paper hard copy prequalification is required to be submitted PRIOR to the bid opening. The proper prequalification form must be sent to the DOT to establish prequalification and remain valid prior to the deadline for prequalification indicated below. Prequalification’s submitted after the deadline will be processed but a bid from that firm will not be opened for any project where the deadline has been exceeded. The following prequalification is required for this contract: The Bureau of Project Development “Prequalification Statement” (AKA: “Highways”) will apply. The proper forms can be found at: https://wisconsindot. gov/Pages/doing-bus/contractors/hcci/ prequal.aspx Bid proposals will be opened only from those firms that have established their qualifications for the work being bid upon. If a prospective bidder has previously submitted hold a current and valid (not expired or revoked), proper statement and received prior approval from the department, a re-submittal for this project is not required. Any prospective bidder who has not previously established their qualifications must file a pre-qualification statement on the proper forms and be received by the department no later than 12:00 noon, local time, Friday, February 21, 2025. Only prime or general contractors submitting the bid need to be prequalified; subcontractors do not need to be prequalified. The qualification statement is a sworn statement and consist of information relating to financial ability, equipment, and experience in the work prescribed in this proposal. The statement shall be in writing on the proper standard form furnished by the department. The department will evaluate the statement and determine acceptability prior to bid acceptance. Failure to establish prequalification as stipulated will result in the bid not being opened and/or rejected. Federal Requirements: This project is federally funded and federal provisions and requirements apply. Federal provisions made part of, but not limited to this contractinclude: Buy American Preference, Federal Tax Certification, Foreign Trade Restriction, Davis Bacon, Affirmative Action, Governmentwide Debarment and Suspension, Governmentwide Requirements for Drug-free Workplace. Hours of labor and minimum wage rates: Pursuant to regulations provided by applicable federal and/or state laws, the hours of labor and minimum wage rates are set forth in the proposal. Affirmative action: The department hereby notifies all bidders that it will affirmatively insure that in any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, sex, or national origin in consideration for an award. Affidavit of non-collusion: A required affidavit of non-collusion will be incorporated as part of the proposal for each prospective bidder. Failure to complete and sign the sworn statement makes the bid non-responsive and ineligible for award consideration. By completing the electronic signature and submitting the proposal,each bidder by or on behalf of the person, firm, association, or corporation submitting the bid, certifies that such person, firm, association, or corporation has not, either directly or indirectly, entered into agreement, participated in any collusion, or otherwise taken any action, in restraint of free competitive bidding in connection with the submitted bid. This sworn statement shall be executed and sworn to by the bidder before a person who is authorized by the laws of the state to administer oaths. Pre-bid conference: A pre-bid conference will be held on Thursday, February 20, 2025, at 1:00 PM at the Waupaca Municipal Airport Terminal Building and via Microsoft Teams using the following details. Microsoft Teams meeting Join on your computer, mobile app or room device Meeting ID: 281 259 250 262 Passcode: Qi2TT745 Or Dial in by phone (audio only) +1 612-268-4437United States, Minneapolis Phone Conference ID: 291 465 509# A physical visit of the site may be authorized by the airport on a case-by-case basis and must be scheduled and coordinated with airport management. Questions arising from site visits shall be submitted by email to the contact person below. Answers will be provided to all plan holders via a subsequent addendum. The purpose of the meeting and site visit will be to familiarize all concerned persons with the project and conditions at the airport. For further information, contact Kaitlyn Schlosser at 920-830-6183, email Kaitlyn.Schlosser@westwoodps.com. City of Waupaca, Wisconsin Represented by Kristina Boardman, Secretary Department of Transportation Sponsor's Authorized Agent kms 518Edeve.dot/r.10/18/2024 Publish Feb. 13 & 20, 2025 WNAXLP

Advertisement for Electronic Bids For Construction at Waupaca Municipal Airport Waupaca, Wisconsin Project no. AIP-15/PCZ1007 THIS PROJECT WILL BE ELECTRONICALLY BID. Paper bids will NOT be accepted or allowed. Sealed ELECTRONIC proposals for the work described herein will be received until 2:00 p.m., local time, Thursday, March 6, 2025, by the Wisconsin Department of Transportation, Bureau of Aeronautics, on behalf of the Secretary, authorized agent for City of Waupaca, in accordance with Wis. Stat. §114.32(3). Bids will be unsealed (electronically opened) as provided above and will be publicly read. The bid opening will be broadcast live via Teams. The correct meeting and call-in information for the bid opening is: Microsoft Teams meeting Join on your computer, mobile app or room device Meeting ID: 273 385 39796 Passcode: tLjwfv Or Dial in by phone (audio only) +1 608-571-2209 United States, Madison Phone Conference ID: 186 780 348# Bid results will be posted as soon as practicable after the close of bids. The bid results will be postedto the Bureau of Aeronautics’ website and BidExpress.com here: https://wisconsin dot.gov/Pages/doing-bus/aeronautics/ airports/arpt-bidinfo.aspx https://bidexpress.com/businesses/5167 1/home Electronic Bid submittal: Bids must be submitted via the bidexpress.com bidding service. No paper bids will be accepted. Bids will not be accepted past the established deadline for the close of bids. Description of work: Base bid: Provide and install 7-unit T-Hangar building including foundations, civil, metal building, and associated electrical. Alternate #1: Provide and install standing-seam metal roof in lieu of screw-down roofing for base bid 7-unit building. Alternate #2: Provide and install one additional bay including additional foundations, civil, metal building, and electrical to be an 8-unit building. Alternate #3: Provide and install standing-seam metal roof in lieu of screw-down roofing for one additional bay. This alternate will be awarded with Alternate #2 Alternate #4: Provide and install one additional bay including additional foundations, civil, metal building, and electrical to be a 9-unit building. This alternate will be awarded with Alternate #2 Alternate #5: Provide and install standing-seam metal roof in lieu of screw-down roofing for one additional bay. This alternate will be awarded with Alternates #1, #2, #3 & #4 Estimate of major quantities: T-hangar building – 1 LS DBE Goal: N/A Contract Completion Time: 120 Working Days Proposals: Proposal forms are included with the plans and specifications, and are subject to the provisions of Wis. Stat.§66.0901(7). Plans and specifications: Plans and specifications can be obtained free of charge and at the following site: https://bidexpress.com/businesses/5 1671/home Proposal ELECTRONIC Submittal: This contract is being electronically bid. The bid template within BidExpress.com platform established for the project includes all elements required to be submitted with the contract. Required fields are established within the template. Automatic checking of the bid proposal will identify if any required fields are missing and alert the bidder to complete the missing information prior to final submission. Submission of an incomplete bid will result in the bid not being opened, and/or rejected as non-responsive. Plan holder registration required: Plans and specifications are available to anyone after completing a simple registration. There is NO cost to obtain a registration. Registration is required to be recorded asa plan holder. Registered plan holders will be notified of important project information such as issuance of addendums or other critical information. Only the prime or general contractor selecting to submit a bid is required to obtain additional Digital ID credentials. Please contact BidExpress support for registration assistance at, Phone: (888)-352-2439 / Email: support@bidexpress.com. Bidder Digital ID Required: Firms who select to submit a bid MUST also obtain a free digital ID in addition to registering. Obtaining a digital ID is relatively quick, however it may take a couple of days to complete the process. Please request and obtain registration and digital ID’s as early as possible to not jeopardize your ability to submit a bid. There is NO cost to obtain a digital ID. Please contact BidExpress support for Digital ID assistance at, Phone: (888)-352-2439 / Email: support@bidexpress.com. Proposal guaranty: A bid security in the amount of 5% of the total amount of the bid is required for the contract. Each proposal must be accompanied by a bid bond, certificate of annual bid bond, a certified check, bank's draft, bank's check, or postal money order made payable to the Wisconsin Department of Transportation Secretary for 5% of the total amount bid. The electronic template will allow the following options for meeting the proposal guaranty. E-Verify bid bond (Surety2000 &SurePath), uploading a copy of the bid bond or certificate of annual bid bond, certified check, bank draft, or money order. Any bid security, other than a E-verified bond or certificate of annual bid bond is provided, the department will require that the apparent two lowest bidders to mail or hand-deliver the original bond, certified check, bank draft, or money order to the Bureau of Aeronautics by close of business two business days following the close of bids and must be received by the Bureau of Aeronautics no later than 5 days from the posting of the bid results. Qualification of bidders: IMPORTANT: A paper hard copy prequalification is required to be submitted PRIOR to the bid opening. The proper prequalification form must be sent to the DOT to establish prequalification and remain valid prior to the deadline for prequalification indicated below. Prequalification’s submitted after the deadline will be processed but a bid from that firm will not be opened for any project where the deadline has been exceeded. The following prequalification is required for this contract: TWO prequalification methods are acceptable for this project. EITHER Bureau of Aeronautics "Statement of Bidder's Qualifications and Experience" (AKA: “Short form”) will apply. OR the Bureau of Project Development "Prequalification Statement" (AKA: “Highways”).If your firm does not already hold a valid WisDOT highways prequalification and you do not expect to bid WisDOT highways projects in the future, please complete the simplified Bureau of Aeronautics “short form Bid proposals will be opened only from those firms that have established their qualifications for the work being bid upon. If a prospective bidder has previously submitted hold a current and valid (not expired or revoked), proper statement and received prior approval from the department, a re-submittal for this project is not required. Any prospective bidder who has not previously established their qualifications must file a pre-qualification statement on the proper forms and be received by the department no later than 12:00 noon, local time, Friday, February 21, 2025. Only prime or general contractors submitting the bid need to be prequalified; subcontractors do not need to be prequalified. The qualification statement is a sworn statement and consist of information relating to financial ability, equipment, and experience in the work prescribed in this proposal. The statement shall be in writing on the proper standard form furnished by the department. The department will evaluate the statement and determine acceptability prior to bid acceptance. Failure to establish prequalification as stipulated will result in the bid not being opened and/or rejected. Federal Requirements: This project is federally funded and federal provisions and requirements apply. Federal provisions made part of, but not limited to this contractinclude: Buy American Preference, Federal Tax Certification, Foreign Trade Restriction, Davis Bacon, Affirmative Action, Governmentwide Debarment and Suspension, Governmentwide Requirements for Drug-free Workplace. Hours of labor and minimum wage rates: Pursuant to regulations provided by applicable federal and/or state laws, the hours of labor and minimum wage rates are set forth in the proposal. Affirmative action: The department hereby notifies all bidders that it will affirmatively insure that in any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, sex, or national origin in consideration for an award. Affidavit of non-collusion: A required affidavit of non-collusion will be incorporated as part of the proposal for each prospective bidder. Failure to complete and sign the sworn statement makes the bid non-responsive and ineligible for award consideration. By completing the electronic signature and submitting the proposal,each bidder by or on behalf of the person, firm, association, or corporation submitting the bid, certifies that such person, firm, association, or corporation has not, either directly or indirectly, entered into agreement, participated in any collusion, or otherwise taken any action, in restraint of free competitive bidding in connection with the submitted bid. This sworn statement shall be executed and sworn to by the bidder before a person who is authorized by the laws of the state to administer oaths. Pre-bid conference: A pre-bid conference will be held on Thursday, February 20, 2025, at 2:00 PM at the Waupaca Municipal Airport Terminal Building and via Microsoft Teams using the following details. Microsoft Teams meeting Join on your computer, mobile app or room device Meeting ID: 281 259 250 262 Passcode: Qi2TT745 Or Dial in by phone (audio only) +1 612-268-4437United States, Minneapolis Phone Conference ID: 291 465 509# A physical visit of the site may be authorized by the airport on a case-by-case basis and must be scheduled and coordinated with airport management. Questions arising from site visits shall be submitted by email to the contact person below. Answers will be provided to all plan holders via a subsequent addendum. The purpose of the meeting and site visit will be to familiarize all concerned persons with the project and conditions at the airport. For further information, contact Cari Bodoh at 920-830-6130, email cari.bodoh@westwoodps.com City of Waupaca, Wisconsin Represented by Kristina Boardman, Secretary Department of Transportation Sponsor's Authorized Agent kms 518Edeve.dot/r.10/18/2024 Publish Feb. 13 & 20, 2025 WNAXLP

Advertisement for Electronic Bids For equipment at Clintonville Municipal Airport Clintonville, Wisconsin Project no. CLI1005 THIS PROJECT WILL BE ELECTRONICALLY BID. Paper bids will NOT be accepted or allowed. Sealed ELECTRONIC proposals for the work described herein will be received until 2:00 p.m., local time, Thursday, March 6, 2025, by the Wisconsin Department of Transportation - Bureau of Aeronautics, on behalf of the Secretary of Transportation, the authorized agent for City of Clintonville, in accordance with Wis. Stat. §114.32(3). Bids will be unsealed (electronically opened) as provided above and will be publicly read. The bid opening will be broadcast live via Teams. The correct meeting and call-in information for the bid opening is: Microsoft Teams meeting Join on your computer, mobile app or room device Meeting ID: 273 385 397 96 Passcode: tLjwfv Or Dial in by phone (audio only) +1 608-571-2209 Phone Conference ID: 186 780 348# Bid results will be posted as soon as practicable after the close of bids. The bid results will be posted to the Bureau of Aeronautics’ website here as well as BidExpress.com: https://wisconsindot.gov/Pages/doing- bus/aeronautics/airports/arpt- bidinfo.aspx https://bidexpress.com/businesses/5167 1/home Electronic Bid submittal: Bids must be submitted via the bidexpress.com bidding service. No paper bids will be accepted. Bids will not be accepted past the established deadline for the close of bids. Description of equipment: Industrial Loader and associated snow removal attachments Contract Completion Time: 360 Calendar Days Proposals/specifications: Proposal forms are included with the specifications, and are subject to the provisions of Wis. Stat. §66.0901(7). Plans and specifications: Plans and specifications can be obtained free of charge and at the following site: https://bidexpress.com/businesses/516 71/home Proposal ELECTRONIC Submittal: This contract is being electronically bid . The bid template within BidExpress.com platform established for the project includes all elements required to be submitted with the contract. Required fields are established within the template. Automatic checking of the bid proposal will identify if any required fields are missing and alert the bidder to complete the missing information prior to final submission. Submission of an incomplete bid will result in the bid not being opened, and/or rejected as non-responsive. Plan holder registration required: Plans and specifications are available to anyone after completing a simple registration. There is NO cost to obtain a registration. Registration is required to be recorded as a plan holder. Registered plan holders will be notified of important project information such as issuance of addendums or other critical information. Only the prime or general contractor selecting to submit a bid is required to obtain additional Digital ID credentials. Please see the BOA website notice 2 for information on how to register. https://wisconsindot.gov/Documents/doi ng-bus/aeronautics/airports/aerobidme m2.pdf Bidder Digital ID Required: Firms who select to submit a bid MUST also obtain a free digital ID in addition to registering. Obtaining a digital ID is relatively quick, however it may take a couple of days to complete the process. Please request and obtain registration and digital ID’s as early as possible to not jeopardize your ability to submit a bid. There is NO cost to obtain a digital ID. Please see the BOA website Notice 2 for information on how to obtain a digital ID. https://wisconsindot.gov/Documents/doi ng-bus/aeronautics/airports/aerobidme m2.pdf Cost to bid: There are two options for bidders to submit bids: A cost of $35 per project, or a monthly subscription wherein the bidder is able to submit bids for all projects in bidexpress.com system for $50 per month. Subscriptions can be turned on and off at any time by the registered user. Only the prime or general contractor submitting a bid are responsible for payment. Proposal guaranty: A bid security in the amount of 5% of the total amount of the bid is required for the contract. Each proposal must be accompanied by a bid bond, certificate of annual bid bond, a certified check, bank's draft, bank's check, or postal money order made payable to the Wisconsin Department of Transportation Secretary for 5% of the total amount bid. The electronic template will allow the following options for meeting the proposal guaranty. E-Verify bid bond (Surety2000 & SurePath), uploading a copy of the bid bond or certificate of annual bid bond, certified check, bank draft, or money order. Any bid security, other than a E-verified bond or certificate of annual bid bond is provided, the department will require that the apparent two lowest bidders to mail or hand-deliver the original bond, certified check, bank draft, or money order to the Bureau of Aeronautics by close of business two business days following the close of bids and must be received by the Bureau of Aeronautics no later than 5 days from the posting of the bid results. Affidavit of non-collusion: The required affidavit of non-collusion will be incorporated as part of the proposal cover provided to each prospective bidder. Failure to complete the sworn statement will make the bid non-responsive and not eligible for award consideration. By signing the proposal cover each bidder by, or on behalf of the person, firm, association, or corporation submitting the bid, certifies that such person, firm, association, or corporation has not, either directly or indirectly, entered into agreement, participated in any collusion, or otherwise taken any action, in restraint of free competitive bidding in connection with the submitted bid. This sworn statement will be executed and sworn to by the bidder before a person who is authorized by the laws of the state to administer oaths. Pre-bid conference: A pre-bid conference will be held on February 20 at 9:00am will be conducted by teleconference in accordance with best practices for COVID19 social distancing recommendations. (+1 608-571-2209, 640944362#). A physical visit of the site may be authorized by the airport on a case by case basis and must be scheduled and coordinated with airport management. Questions arising from site visits shall be submitted by email to the contact person below. Answers will be provided to all plan holders via a subsequent addendum. The purpose of the meeting and site visit will be to familiarize all concerned persons with the bid specifications. For further information, contact Matthew Brynick, (608) 266-2079, matthew.brynick@dot.wi.gov at the Wisconsin Bureau of Aeronautics. Clintonville, Wisconsin Represented by Kristina Boardman, Secretary Department of Transportation Sponsor's Authorized Agent MTB 700adev.dotr.10/18/2024 Publish Feb. 20 & 27, 2025 WNAXLP

Allouez WNAXLP ADVERTISEMENT FOR BIDS PROJECT: Webster Park and Optimist Park Parking Lot Improvements Village of Allouez BID DEADLINE: March 13, 2025 1:00 PM, Local Time NOTICE Sealed bids for the above project will be received by the Village of Allouez until the Bid Deadline. Bids shall be submitted in electronic format through Quest vBid. Immediately after the Bid Deadline, bids will be publicly opened and read aloud, online through electronic means. The bid opening for this project will be conducted using Microsoft Teams. Bidders and other interested parties may call the teleconference number: (715) 318-5006, conference ID: 245692978#, on the day of the bids to hear bids results announced. The teleconference line will be open 15 minutes before bids are due. Bids will be opened after the bid deadline. In general, the project consists of the curb and gutter and asphalt pavement for a turnaround and new asphalt trails at Optimist Park and construction of a new parking lot and asphalt trails at Webster Park in the Village of Allouez. Work at both parks may include miscellaneous storm sewer work, site grading, concrete curb and gutter, asphalt paving, pavement markings, and a detention basin. A formal pre-bid meeting to examine the site will not be held. The sites are public parks. Contractors may view the site at their convenience. A single prime bid will be received for the work. BID SECURITY Bids must be accompanied by bid security in the amount of 5% of the maximum bid amount. Bid and bid security may not be withdrawn for a period of 60 days after the Bid Deadline. Bid security will be retained if the Bidder is awarded the Work and fails to execute the Agreement and furnish 100% Performance and Payment Bonds. QUALIFICATIONS Bidders shall be experienced in this type of work and shall submit a Statement of Bidder's Qualifications with their bid. RIGHTS RESERVED Owner reserves the right to reject any or all bids and to waive informalities in any bid. BIDDING DOCUMENTS Bidding documents may be obtained in PDF electronic format by download from the Quest Construction Data Network website, accessible via www.AyresAssociates.com by clicking on the "Bidding" link, for a non-refundable fee of $64.00. Published by authority of: Village of Allouez Publish 02.21.25 & 02.28.25 WNAXLP

CITY OF MAYVILLE The City of Mayville is requesting sealed bids from qualified bidders for Shelter Maintenance and/or Repair at four (4) park locations and one (1) alternate location throughout the City of Mayville including fascia, soffit, shingles and/or vinyl siding. Request for bid packets will be available starting February 20, 2025 on the City of Mayville website at https:www.mayvillecity.com and may also be obtained from the Park’s Director Jacob Schellpfeffer at jschellpffefer@mayvillcity.com Sealed bids should be marked “Sealed Bid Shelter Maintenance” and must be received in the Mayville City Hall, 15 S School Street, Mayville WI 53050 by 10:00 a.m. on or before Thursday, March 27, 2025. A Pre-Bid Walkthrough is scheduled for February 27, 2025 starting a 8:00 a.m. at Ziegler Park, 762 Kekoskee Street, Mayville. Each bid must be accompanied by a bid bond, certified check or bank cashier’s check as bid security, in the sum of five percent (5%) of the bid, payable to the City of Mayville as a guarantee. In case the successful bidder shall fail to execute the Contract, the amount of the bid security shall be forfeited to the City of Mayville as liquidated damages. The City of Mayville reserves the right to refuse any and all bids or to accept any bid considered most advantageous to the City of Mayville. All Bids shall remain subject to acceptance for sixty (60) days. The City of Mayville encourages the participation of minority, women-owned and disadvantaged business enterprises. Anastasia Gonstead City of Mayville Clerk 2/20 WNAXLP

CITY OF WEYAUWEGA REQUEST FOR PROPOSALS - AUDIT & NON-AUDIT SERVICES Release Date: February 17, 2025 Closing Date and Time: Friday, March 28, 2025 at 12:00 pm CST The City of Weyauwega {City) is issuing a Request for Proposal {RFP) for the purpose of retaining a Certified Public Accounting firm (Firm) to provide auditing and specified non-audit services for the City. The agreement will be for a five-year period, to include audit years 2025- 2029. To be considered, five (5) copies of the sealed proposal and one (1) electronic copy must be received at the City of Weyauwega City Hall, by 12:00 pm on Friday, March 28, 2025. No late proposals will be accepted. A complete copy of the Request for Proposal can be found on the City of Weyauwega website at https://www.city ofweyauwega-wi.gov/government . Notice is given under my hand and the Corporate Seal of the City of Weyauwega on this 18th day of February 2025. Rebecca Loehrke, City Clerk Publish Feb. 27, 2025 WNAXLP

Howard WNAXLP SECTION 00020 ADVERTISEMENT FOR BIDS Village of Howard 1336 Cornell Road Green Bay, WI 54313-8923 Sealed bids for the Hazel Estates 3rd Addition and Marley Meadows Utility & Roadway Construction will be received by the Village of Howard at the Public Works Facility, 1336 Cornell Road, Green Bay, WI 54313-8923, until March 3, 2025, at 1:30 P.M., CT, and shall include the following approximate quantities: 3150 L.F. - Sanitary Sewer 20000 C.Y. - Excavation & Grading 3900 L.F. - Storm Sewer 15000 Tons - Crushed Aggregate 3350 L.F. - Watermain 6750 L.F. - Curb & Gutter 1500 Tons - Asphaltic Pavement 34000 S.F. - Concrete Sidewalk The project is scheduled to be completed by August 22, 2025, Utility work and October 17, 2025 Roadway work. Bids will be publicly opened and read aloud. The Bidding Documents, consisting of Advertisement for Bids, Instructions to Bidders, General Conditions, Supplementary Conditions, Bid Bond, Agreement, Payment and Performance Bonds, Notice of Award, Notice to Proceed, Addenda, Certificate of Substantial Completion, and Drawings and Specifications, may be examined at the following locations: Issuing Office: Village of Howard Public Works Facility 1336 Cornell Road Green Bay, WI 54313 (920)434-4060 Bidding and the award of work will be in accordance with the provisions of Section 61.55 and 66.0901. Each proposal must be accompanied by a Bid bond or certified check equivalent to 5% of the maximum proposal. The Owner reserves the right to reject any or all bids, waive or not waive any informalities in the bids received, and to accept any proposal, which they deem most favorable to the interest of the Owner. No bidder may withdraw his bid within 150 days after the actual date of the opening thereof. Complete digital project bidding documents are available at www.questcdn.com . Bidders shall download the digital plan documents for $30.00 by inputting Quest project #9541399 on the website’s Project Search. Please contact QuestCND.com at 952-233-1632 or info@questcdn.com for assistance in free membership registration, downloading, and working with this digital project information. No paper plan sets will be provided. Please contact us at(920)434-4060 if you have any questions. Josh Gerrits, P.E. Village Engineer Publication Date: 02/14/2025 Publication Date: 02/21/2025 WNAXLP

Luxemburg WNAXLP FARMLAND FOR RENT 12.5 acres of farmland in the Town of Luxemburg on Lowell Road, for a three-year period beginning March 1, 2025 thru February 28, 2028. Sealed bids must be submitted no later than 5:00 PM on Friday, February 21, 2025. Rent must be paid on or before March 1 of each year. The Town Board reserves the right to accept or reject any or all bids. Bids can be mailed to: Town of Luxemburg, P.O. Box 28, Luxemburg, WI 54217. Attn: Linda Jonet Bids will be opened at our Town Meeting on February 26, 2025, at 7:00 PM. Glenda Daul, Town Clerk Publish 02.01.25, 02.08.25 & 02.15.25 WNAXLP

SECTION 00 11 13.00 ADVERTISEMENT FOR BIDS TOWN OF CALEDONIA Waupaca County, Wisconsin OWNER - The Town of Caledonia acting through its Town Board, hereby gives notice that sealed Bids will be received in the Town Hall for the following described project. PROJECT The work shall consist of furnishing and installing trees and shrubs in Gruetzmacher Park on Bean City Road in the Town of Caledonia. The project is being funded by a Knowles-Nelson Stewardship Grant for development of the park. Bids will be received on the following Contract: Contract No. C0069-09-24-00534.02 GRUETZMACHER PARK TREE PLANTING TIME Sealed Bids will be received until 10:00 a.m., local time, on Thursday, February 27, 2025, in the Town of Caledonia Town Hall E9181 State Road 96, Readfield, WI 54969, at which time and place all Bids will be publicly opened and read aloud. BIDS All Bids shall be addressed to Natalie Snyder, Clerk, Town of Caledonia Town Hall, E9181 State Road 96, Readfield, WI 54969. Bids shall be sealed and shall have the name and address of the Bidder and the Contract for which the Bid is being submitted on the outside of the envelope. All Bidders shall Bid in accordance with and upon the Bid Forms included in the Contract Documents. EXAMINATION OF BIDDING DOCUMENTS The Project Documents are on file for inspection at the offices of McMahon Associates, Inc., 1445 McMahon Drive, Neenah, Wisconsin 54956. PROCUREMENT OF BIDDING DOCUMENTS In order to be a ‘Plan Holder’ or ‘Bidder’, each firm or organization shall either download Bidding Documents from the McMahon Associates, Inc. website ( www.mcmgrp.com ) utilizing QuestCDN eBidDocTMor by obtaining a hard copy as designated in this Advertisement For Bids. Complete digital Bidding Documents are available at www.mcmgrp.com or www.questcdn.com . Digital Bidding Documents may be downloaded for a non-refundable $40.00 by inputting Quest Project No. 9539266 on the website’s Project Search page. On-line bid submission is available for this project for a non-refundable $55.00. Contact QuestCDN.com at 952-233-1632 or info@questcdn.com for assistance in free membership registration, downloading, and working with this digital project information. An optional ‘paper’ set of Bidding Documents is also available for a non-refundable $60.00 (approximate cost) plus applicable sales tax and shipping. Contact Blue Print Service Company for more information on paper Bidding Documents and payment options available. Full-size Drawings are available upon request at an additional cost. Neither the Owner nor McMahon Associates, Inc. shall be held responsible for the scale of downloaded Drawings. Printed Drawings obtained from Blue Print Service Company shall be considered to be scalable. Blue Print Service Company 2350 West Pershing Street; Suite A Appleton, WI 54914 920-733-4539 - Telephone 920-733-1438 - Fax bps@blueprintservice.com - Email Blue Print Service Company 2201 South Oneida Street, Suite 8 Green Bay, WI 54304 920-494-4539 - Telephone 920-494-4551 - Fax bps@blueprintservice.com - Email BID SECURITY No Bid shall be received unless accompanied by a Certified Check or satisfactory Bid Bond payable to the Town of Caledonia in an amount not less than 5% of the maximum Bid as a guarantee that, if the Bid is accepted, the Bidder will execute and file the Contract, Performance/Payment Bonds and Insurance Certification, as required by the Contract Documents, within 15-days after the Notice of Award. BID REJECTION The OWNER reserves the right to reject any and all Bids, waive any informalities in Bidding or to accept the Bid or Bids which best serves the interests of the Town of Caledonia. WITHDRAWAL OF BIDS No Bid shall be withdrawn for a period of 90-days after the scheduled opening without the consent of the OWNER. GOVERNING LAWS & REGULATIONS The Contract letting shall be subject to the provisions of Sections66.0901, 66.0903 and 779.16 of the Wisconsin Statutes. Published by the authority of the Town of Caledonia acting through its Town Board. TOWN OF CALEDONIA | Waupaca County, Wisconsin Natalie Snyder, Clerk Publish February 13 & 20, 2025 WNAXLP

TOWN OF AUBURN PUBLIC TEST NOTICE IS HEREBY GIVEN that the public test of the Dominion ICE Voting Equipment to be used at the Election on February 18, 2025 will be conducted at the Auburn Town Hall, W1728 Sunset Drive, Campbellsport, Wisconsin at 3:00 p.m. on February 12, 2025. This public test is open to the general public, Chapter 5, Sec. 5.84 Wisconsin Statues. Bonnie Berg, CMC Town Clerk 2/6 WNAXLP

VOTING BY ABSENTEE BALLOT Any qualified elector who is unable or unwilling to appear at the polling place on Election Day may submit a request to vote an absentee ballot to their municipal clerk. A qualified elector is any U.S. citizen who: • will be 18 years of age or older on Election Day • has resided in the ward or municipality where they wish to vote for at least 28 consecutive days before the election. The elector must also be registered to vote to receive an absentee ballot. Proof of identification must be provided before an absentee ballot may be issued. Making application to receive an absentee ballot by mail Contact your municipal clerk and request that an application for an absentee ballot be sent to you for the primary or election or both. You may make written application to your municipal clerk for an absentee ballot by mail, by fax, by email or at MyVote.wi.gov. Or you may apply in person at the clerk’s office during the In-Person Absentee Voting period listed below. Your written request must include: 1. your voting address within the municipality where you wish to vote 2. the address where the absentee ballot should be sent, if different from the address above 3. your signature 4. a copy of your photo identification* The deadline for making application to receive an absentee by mail is 5:00 p.m., on Thursday, March 27, 2025 *Voters who are indefinitely confined due to age, illness, infirmity, or disability may not be required to provide photo ID. If this applies to you, contact the municipal clerk regarding deadlines for requesting and submitting an absentee ballot. **Special absentee voting application provisions apply to electors who are indefinitely confined, in the military, hospitalized, or serving as a sequestered juror. If this applies to you, contact the municipal clerk regarding deadlines for requesting and submitting an absentee ballot. Voting an absentee ballot in person You may also request and vote an absentee ballot in the clerk's office or other specified location during the days and hours specified for casting an absentee ballot in person. Peggy Johnson, Clerk-Treas. City of Clintonville 50 Tenth Street Clintonville, WI 54929 Phone: (715) 823-7600 Monday – Thursday: 7:30 a.m. to 4:30 p.m. Friday: 7:30 a.m. to 1:30 p.m. (By appointment) The first day to vote any absentee ballot in the clerk’s office is Tuesday, March 18, 2025. The last day to vote an absentee ballot in the clerk’s office is Friday, March 28, 2025. No in-person absentee voting may occur on the day before the election. The municipal clerk will deliver voted ballots returned on or before Election Day to the proper polling place or counting location before the polls close on Tuesday, April 1, 2025. Any ballots received after the polls close will not be counted. Publish March 6, 2024 WNAXLP

VOTING BY ABSENTEE BALLOT Any qualified elector who is unable or unwilling to appear at the polling place on Election Day may submit a request to vote an absentee ballot to their municipal clerk. A qualified elector is any U.S. citizen who: • will be 18 years of age or older on Election Day. • has resided in the ward or municipality where they wish to vote for at least 28 consecutive days before the election. The elector must also be registered to vote to receive an absentee ballot. Proof of identification must be provided before an absentee ballot may be issued. Making application to receive an absentee ballot by mail Contact your municipal clerk and request that an application for an absentee ballot be sent to you for the primary or election or both. You may make written application to your municipal clerk for an absentee ballot in person, by mail, by fax, by email or at MyVote.wi.gov. Your written request must include: 1. your voting address within the municipality where you wish to vote 2. the address where the absentee ballot should be sent, if different from the address above 3. your signature 4. a copy of your photo identification* The deadline for making application to receive an absentee ballot by mail is: 5:00 p.m. on the fifth day before the election, Friday, February 14, 2025. *Voters who are indefinitely confined due to age, illness, infirmity, or disability may not be required to provide photo ID. If this applies to you, contact the municipal clerk regarding deadlines for requesting and submitting an absentee ballot. **Special absentee voting application provisions apply to electors who are indefinitely confined, in the military, hospitalized, or serving as a sequestered juror. If this applies to you, contact the municipal clerk regarding deadlines for requesting and submitting an absentee ballot. Voting an absentee ballot in person You may also request and vote an absentee ballot in the clerk's office or other specified location during the days and hours specified for casting an absentee ballot in person. Laura J. Krogwold 715-445-2913 180 S. Main St., Iola, WI 54945 Monday & Tuesday 8 AM to 5 PM Wednesday & Thursday: 8 AM to 3 PM Friday: 8 AM to 1 PM The first day to vote an absentee ballot in the clerk’s office is: February 4, 2025 The last day to vote an absentee ballot in the clerk's office is: February 14, 2025 No in-person absentee voting may occur on the day before the election. The municipal clerk will deliver voted ballots returned on or before Election Day to the proper polling place or counting location before the polls close on (insert date of primary or election). Any ballots received after the polls close will not be counted. Publish Jan. 16, 2025 WNAXLP

West De Pere WNAXLP EXHIBIT B NOTICE OF ELECTION SCHOOL DISTRICT OF WEST DE PERE APRIL 1, 2025 Referendum Details At an election in the School District of West De Pere on Tuesday, Aprill, 2025, the following question will be submitted to a vote of the people: "Shall the School District of West De Pere, Brown and Outagamie Counties, Wisconsin be authorized to issue pursuant to Chapter 67 of the Wisconsin Statutes, general obligation bonds in an amount not to exceed $9,925,000 for the public purpose of paying the cost of a school building and facility improvement project consisting of: construction of an addition for technical education space, renovations and site improvements at the High School; district wide capital maintenance and building infrastructure improvements; and acquisition of furnishings, fixtures and equipment?" A copy of the entire text of the resolution directing submission of the question set forth above to the electorate and information concerning District boundaries can be obtained from the District Clerk at the School District offices located at 400 Reid Street, Suite W, De Pere, Wisconsin. Additional Information Acceptable photo ID will be required to vote at this election. If you do not have a photo ID you may obtain a free ID for voting from the Division of Motor Vehicles. Persons with questions regarding the referendum election should contact Dr. Jason Lau, District Administrator. Done in the School District of West De Pere on February 28, 2025 Barbara Van Deurzen District Clerk Publish 02.21.25 WNAXLP

ADVERTISEMENT FOR BIDS Compost/Topsoil Screening The City of Merrill, Lincoln County, Wisconsin, will receive sealed bids for Compost/Topsoil Screening. Bids will be accepted until 2 pm, March 20th, 2025, at the City of Merrill City Hall, at which time they will be opened, read aloud and placed on file for further action. Bids shall be returned to the City Clerk’s office located at 1004 E First Street, Merrill, WI 54452. Bid documents will be available from the City Clerk’s Office Monday February 17th, 2025 or on our city website ci.merrill.wi.us Published February 13 & 20, 2025 WNAXLP

Advertisement for Electronic Bids ( Two weeks 2/19-2/26/25 ) For Construction at Eagle River Union Airport Eagle River, Wisconsin Project no. EGV1010 / AIP-20 THIS PROJECT WILL BE ELECTRONICALLY BID. Paper bids will NOT be accepted or allowed. Sealed ELECTRONIC proposals for the work described herein will be received until 2:00 p.m., local time, Thursday, March 6, 2025, by the Wisconsin Department of Transportation, Bureau of Aeronautics, on behalf of the Secretary, authorized agent for the City of Eagle River, in accordance with Wis. Stat. §114.32(3). Bids will be unsealed (electronically opened) as provided above and will be publicly read. The bid opening will be broadcast live via Teams. The correct meeting and call-in information for the bid opening is: Microsoft Teams meeting Join on your computer, mobile app or room device Meeting ID: 273 385 397 96 Passcode: tLjwfv Or Dial in by phone (audio only) +1 608-571-2209 United States, Madison Phone Conference ID: 186 780 348# Bid results will be posted as soon as practicable after the close of bids. (_______________________________) The bid results will be posted to the Bureau of Aeronautics’ website and BidExpress.com here: https://wisconsindot.gov/Pages/doing-bus/aeronautics/airports/arpt bidinfo.aspx https://bidexpress.com/businesses/51671/home Electronic Bid submittal: Bids must be submitted via the bidexpress.com bidding service. No paper bids will be accepted. Bids will not be accepted past the established deadline for the close of bids. Description of work: Base Bid: Replace airport fence access gates and associated work. Estimate of major quantities: Removing Access Gates, 3 EACH; Removing HMA Pavement, 1100 SY; Removing Fence, 100 LF; Excavation Common, 400 CY; Base Aggregate Dense, 850 TON: Concrete Pavement and Sidewalk, 700 SF; HMA Pavement, 300 TON; Concrete Curb & Gutter, 40 LF; Chain Link Fence, 180 LF; Landscaping and Erosion Mat, 1450 SY; Flexible Polyethylene Duct, 2650 LF; Electrical Cabling, 650 LF; Electrical Handholes, 16 EACH; PVC Duct (including boring), 190 LF; Concrete Bollards, 36 EACH; Vertical Pivot Gates, 3 LS; Gate Lighting, 3 LS Proposals: Proposal forms are included with the plans and specifications, and are subject to the provisions of Wis. Stat. §66.0901(7). Plans and specifications: Plans and specifications can be obtained free of charge and at the following site: https://bidexpress.com/businesses/51671/home Proposal ELECTRONIC Submittal: This contract is being electronically bid . The bid template within BidExpress.com platform established for the project includes all elements required to be submitted with the contract. Required fields are established within the template. Automatic checking of the bid proposal will identify if any required fields are missing and alert the bidder to complete the missing information prior to final submission. Submission of an incomplete bid will result in the bid not being opened, and/or rejected as non-responsive. Plan holder registration required: Plans and specifications are available to anyone after completing a simple registration. There is NO cost to obtain a registration. Registration is required to be recorded as a plan holder. Registered plan holders will be notified of important project information such as issuance of addendums or other critical information. Only the prime or general contractor selecting to submit a bid is required to obtain additional Digital ID credentials. Please contact BidExpress support for registration assistance at, Phone: (888)-352-2439 / Email: support@bidexpress.com. Bidder Digital ID Required: Firms who select to submit a bid MUST also obtain a free digital ID in addition to registering. Obtaining a digital ID is relatively quick, however it may take a couple of days to complete the process. Please request and obtain registration and digital ID’s as early as possible to not jeopardize your ability to submit a bid. There is NO cost to obtain a digital ID. Please contact BidExpress support for Digital ID assistance at, Phone: (888)-352-2439 / Email: support@bidexpress.com. Proposal guaranty: A bid security in the amount of 5% of the total amount of the bid is required for the contract. Each proposal must be accompanied by a bid bond, certificate of annual bid bond, a certified check, bank's draft, bank's check, or postal money order made payable to the Wisconsin Department of Transportation Secretary for 5% of the total amount bid. The electronic template will allow the following options for meeting the proposal guaranty. E-Verify bid bond (Surety2000 & SurePath), uploading a copy of the bid bond or certificate of annual bid bond, certified check, bank draft, or money order. Any bid security, other than a E-verified bond or certificate of annual bid bond is provided, the department will require that the apparent two lowest bidders to mail or hand-deliver the original bond, certified check, bank draft, or money order to the Bureau of Aeronautics by close of business two business days following the close of bids and must be received by the Bureau of Aeronautics no later than 5 days from the posting of the bid results. Qualification of bidders: IMPORTANT: A paper hard copy prequalification is required to be submitted PRIOR to the bid opening . The proper prequalification form must be sent to the DOT to establish prequalification and remain valid prior to the deadline for prequalification indicated below. Prequalification’s submitted after the deadline will be processed but a bid from that firm will not be opened for any project where the deadline has been exceeded. The following prequalification is required for this contract: The Bureau of Project Development “Prequalification Statement” (AKA: “Highways”) will apply. The proper forms can be found at: https://wisconsindot.gov/Pages/doing-bus/contractors/hcci/prequal.aspx Bid proposals will be opened only from those firms that have established their qualifications for the work being bid upon. If a prospective bidder has previously submitted hold a current and valid (not expired or revoked), proper statement and received prior approval from the department, a re-submittal for this project is not required. Any prospective bidder who has not previously established their quali-fications must file a pre- qualification statement on the proper forms and be received by the department no later than 12:00 noon, local time, Friday, February 28, 2025. Only prime or general contractors submitting the bid need to be prequalified; subcontractors do not need to be prequalified. The qualification statement is a sworn statement and consist of information relating to financial ability, equipment, and experience in the work prescribed in this proposal. The statement shall be in writing on the proper standard form furnished by the department. The department will evaluate the statement and determine acceptability prior to bid acceptance. Failure to establish prequalification as stipulated will result in the bid not being opened and/or rejected. Federal Requirements: This project is federally funded and federal provisions and requirements apply. Federal provisions made part of, but not limited to this contract include: Buy American Preference, Federal Tax Certification, Foreign Trade Restriction, Davis Bacon, Affirmative Action, Governmentwide Debarment and Suspension, Governmentwide Requirements for Drug-free Workplace. Hours of labor and minimum wage rates: Pursuant to regulations provided by applicable federal and/or state laws, the hours of labor and minimum wage rates are set forth in the proposal. Affirmative action: The department hereby notifies all bidders that it will affirmatively insure that in any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, sex, or national origin in consideration for an award. Affidavit of non-collusion: A required affidavit of non-collusion will be incorporated as part of the proposal for each prospective bidder. Failure to complete and sign the sworn statement makes the bid non- responsive and ineligible for award consideration. By completing the electronic signature and submitting the proposal, each bidder by or on behalf of the person, firm, association, or corporation sub-mitting the bid, certifies that such person, firm, association, or corporation has not, either directly or indirectly, entered into agreement, participated in any collusion, or otherwise taken any action, in restraint of free competitive bidding in connection with the submitted bid. This sworn statement shall be executed and sworn to by the bidder before a person who is authorized by the laws of the state to administer oaths. Pre-bid conference: A pre-bid conference will be held on Tuesday, February 25, 2025 at 10:00 AM at the Eagle River Union Airport Conference Room. A site visit for those interested will be held after the pre-bid meeting. Additionally, for those unable to attend the meeting in person, a virtual option via Microsoft Teams will be provided and the information to join the meeting is listed below: Microsoft Teams Join the meeting now Meeting ID: 236 100 764 638 Passcode: bQ32fE9o Dial in by phone +1 262-771-1345,,193515047# United States, Kenosha Phone conference ID: 193 515 047# The purpose of the meeting and site visit will be to familiarize all concerned persons with the project and conditions at the airport. For further information, contact Jeremy Roberts, P.E. at (920) 931-0581, email jroberts@msa-ps.com Eagle River, Wisconsin Represented by Kristina Boardman, Secretary Department of Transportation Sponsor's Authorized Agent 2743 WNAXLP

Advertisement for Electronic Bids For Construction at Merrill Municipal Airport Merrill, Wisconsin Project no. RRL1004 (AIP-14) THIS PROJECT WILL BE ELECTRONICALLY BID. Paper bids will NOT be accepted or allowed. Sealed ELECTRONIC proposals for the work described herein will be received until 2:00 p.m., local time, Thursday, March 6th, 2025, by the Wisconsin Department of Transportation, Bureau of Aeronautics, on behalf of the Secretary, authorized agent for City of Merrill, in accordance with Wis. Stat. §114.32(3). Bids will be unsealed (electronically opened) as provided above and will be publicly read. The bid opening will be broadcast live via Teams. The correct meeting and call-in information for the bid opening is: Microsoft Teams meeting Join on your computer, mobile app or room device Meeting ID: 273 385 397 96 Passcode: tLjwfv Or Dial in by phone (audio only) +1 608-571-2209 United States, Madison Phone Conference ID: 186 780 348# Bid results will be posted as soon as practicable after the close of bids. The bid results will be posted to the Bureau of Aeronautics’ website and BidExpress.com here: https://wisconsindot.gov/Pages/doing-bus/aeronautics/airports/arpt-bidinfo.aspx https://bidexpress.com/businesses/51671/home Electronic Bid submittal: Bids must be submitted via the bidexpress.com bidding service. No paper bids will be accepted. Bids will not be accepted past the established deadline for the close of bids. Description of work: Base Bid: Construct Sponsor Owned Box Hangar Estimate of major quantities: Base Bid: Construct Box Hangar 1 LS. DBE Goal: N/A Contract Completion Time: 270 Calendar Days. Proposals: Proposal forms are included with the plans and specifications, and are subject to the provisions of Wis. Stat. §66.0901(7). Plans and specifications: Plans and specifications can be obtained free of charge and at the following site: https://bidexpress.com/businesses/51671/home Proposal ELECTRONIC Submittal: This contract is being electronically bid . The bid template within BidExpress.com platform established for the project includes all elements required to be submitted with the contract. Required fields are established within the template. Automatic checking of the bid proposal will identify if any required fields are missing and alert the bidder to complete the missing information prior to final submission. Submission of an incomplete bid will result in the bid not being opened, and/or rejected as non-responsive. Plan holder registration required: Plans and specifications are available to anyone after completing a simple registration. There is NO cost to obtain a registration. Registration is required to be recorded as a plan holder. Registered plan holders will be notified of important project information such as issuance of addendums or other critical information. Only the prime or general contractor selecting to submit a bid is required to obtain additional Digital ID credentials. Please contact BidExpress support for registration assistance at, Phone: (888)-352-2439 / Email: support@bidexpress.com. Bidder Digital ID Required: Firms who select to submit a bid MUST also obtain a free digital ID in addition to registering. Obtaining a digital ID is relatively quick, however it may take a couple of days to complete the process. Please request and obtain registration and digital ID’s as early as possible to not jeopardize your ability to submit a bid. There is NO cost to obtain a digital ID. Please contact BidExpress support for Digital ID assistance at, Phone: (888)-352-2439 / Email: support@bidexpress.com. Proposal guaranty: A bid security in the amount of 5% of the total amount of the bid is required for the contract. Each proposal must be accompanied by a bid bond, certificate of annual bid bond, a certified check, bank's draft, bank's check, or postal money order made payable to the Wisconsin Department of Transportation Secretary for 5% of the total amount bid. The electronic template will allow the following options for meeting the proposal guaranty. E-Verify bid bond (Surety2000 & SurePath), uploading a copy of the bid bond or certificate of annual bid bond, certified check, bank draft, or money order. Any bid security, other than a E-verified bond or certificate of annual bid bond is provided, the department will require that the apparent two lowest bidders to mail or hand-deliver the original bond, certified check, bank draft, or money order to the Bureau of Aeronautics by close of business two business days following the close of bids and must be received by the Bureau of Aeronautics no later than 5 days from the posting of the bid results. Qualification of bidders: IMPORTANT: A paper hard copy prequalification is required to be submitted PRIOR to the bid opening . The proper prequalification form must be sent to the DOT to establish prequalification and remain valid prior to the deadline for prequalification indicated below. Prequalification’s submitted after the deadline will be processed but a bid from that firm will not be opened for any project where the deadline has been exceeded. The following prequalification is required for this contract: TWO prequalification methods are acceptable for this project. EITHER Bureau of Aeronautics "Statement of Bidder's Qualifications and Experience" (AKA: “Short form”) will apply. OR the Bureau of Project Development "Prequalification Statement" (AKA: “Highways”). If your firm does not already hold a valid WisDOT highways prequalification and you do not expect to bid WisDOT highways projects in the future, please complete the simplified Bureau of Aeronautics “short form”. Bid proposals will be opened only from those firms that have established their qualifications for the work being bid upon. If a prospective bidder has previously submitted hold a current and valid (not expired or revoked), proper statement and received prior approval from the department, a re-submittal for this project is not required. Any prospective bidder who has not previously established their qualifications must file a pre-qualification statement on the proper forms and be received by the department no later than 12:00 noon, local time, Friday, February 28th, 2025. Only prime or general contractors submitting the bid need to be prequalified; subcontractors do not need to be prequalified. The qualification statement is a sworn statement and consist of information relating to financial ability, equipment, and experience in the work prescribed in this proposal. The statement shall be in writing on the proper standard form furnished by the department. The department will evaluate the statement and determine acceptability prior to bid acceptance. Failure to establish prequalification as stipulated will result in the bid not being opened and/or rejected. Federal Requirements: This project is federally funded and federal provisions and requirements apply. Federal provisions made part of, but not limited to this contract include: Buy American Preference, Federal Tax Certification, Foreign Trade Restriction, Davis Bacon, Affirmative Action, Governmentwide Debarment and Suspension, Governmentwide Requirements for Drug-free Workplace. Hours of labor and minimum wage rates: Pursuant to regulations provided by applicable federal and/or state laws, the hours of labor and minimum wage rates are set forth in the proposal. Affirmative action: The department hereby notifies all bidders that it will affirmatively insure that in any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, sex, or national origin in consideration for an award. Affidavit of non-collusion: A required affidavit of non-collusion will be incorporated as part of the proposal for each prospective bidder. Failure to complete and sign the sworn statement makes the bid non-responsive and ineligible for award consideration. By completing the electronic signature and submitting the proposal, each bidder by or on behalf of the person, firm, association, or corporation submitting the bid, certifies that such person, firm, association, or corporation has not, either directly or indirectly, entered into agreement, participated in any collusion, or otherwise taken any action, in restraint of free competitive bidding in connection with the submitted bid. This sworn statement shall be executed and sworn to by the bidder before a person who is authorized by the laws of the state to administer oaths. Pre-bid conference: A pre-bid conference will be held on Wednesday, February 19th, 2025 at 2:30 p.m. at the airport terminal, Merrill Municipal Airport. The purpose of this meeting will be to familiarize all concerned persons with the project and conditions at the airport. Information for attending virtually is as follows: Microsoft Teams Need help? Join the meeting now Meeting ID: 277 276 277 431 Passcode: 5vb3yw7E Dial in by phone +1 323-792-6072,,399346223# United States, Los Angeles Find a local number Phone conference ID: 399 346 223# For organizers: Meeting options | Reset dial-in PIN For further information, contact Karl Kemper at 715-551-5507, email kkemper@becherhoppe.com City of Merrill, Wisconsin Represented by Kristina Boardman, Secretary Department of Transportation Sponsor's Authorized Agent KRK/bmp 518Edeve.dot/r.10/18/2024 Published February 13 & 20, 2025 WNAXLP

BY THE COURT DATE SIGNED: February 10, 2025 Electronically signed by Becky S. Byer Probate Registrar STATE OF WISCONSIN CIRCUIT COURT, LINCOLN COUNTY IN THE MATTER OF THE ESTATE OF Russell J. Ryan Notice Setting Time to Hear Application and Deadline for Filing Claims (Informal Administration) Case No. 25IN14 PLEASE TAKE NOTICE: 1. An application for informal administra-tion was filed. 2. The decedent, with date of birth October 6, 1957, and date of death January 15, 2025, was domiciled in Lincoln County, State of WI, with a mailing address of N2864 Schielke Rd. 3. The application will be heard at the Lincoln County Courthouse, Merrill, Wisconsin, Probate Office, before Becky Byer, Probate Registrar, on March 20, 2025 at 10:00a.m. You do not need to appear unless you object. The application may be granted if there is no objection. 4. The deadline for filing a claim against the decedent's estate is 05-30-2025. 5. A claim may be filed at the Lincoln County Courthouse, Merrill, Wisconsin, Probate Office. 6. This publication is notice to any persons whose names or addresses are unknown. If you require reasonable accommoda-tions due to a disability to participate in the court process, please call 715-536-0342 prior to the scheduled court date. Please note that the court does not provide transportation. Shirley A. Ryan N7054 Grundy Rd Gleason, WI 54435 715-921-4075 Published February 13, 20 & 27, 2025 WNAXLP

BY THE COURT DATE SIGNED: February 10, 2025 Electronically signed by Becky S. Byer Probate Registrar STATE OF WISCONSIN, CIRCUIT COURT, LINCOLN COUNTY IN THE MATTER OF THE ESTATE OF Douglas A. Alderton Amended Notice to Creditors (Informal Administration) Case No. 2025 IN 13 PLEASE TAKE NOTICE: 1. An application for informal administra-tion was filed. 2. The decedent, with date of birth March 7, 1945 and date of death December 26, 2024, was domiciled in Lincoln County, State of WI, with a mailing address of 714 S. State St. APT 6, Merrill, WI, 54452. 3. All interested persons waived notice. 4. The deadline for filing a claim against the decedent's estate is May 30, 2025. 5. A claim may be filed at the Lincoln County Courthouse, Merrill, Wisconsin, Probate Office. Tara Alderton 525 Pelican Street, Rhinelander, WI 54501 715-891-7550 Published February 13, 20 & 27, 2025 WNAXLP

BY THE COURT DATE SIGNED: January 30, 2025 Electronically signed by Becky S. Bye r Probate Registrar STATE OF WISCONSIN CIRCUIT COURT, LINCOLN COUNTY IN THE MATTER OF THE ESTATE OF Kevin M. Delp Notice to Creditors (Informal Administration) Case No. 2025-IN-11 PLEASE TAKE NOTICE: 1. An application for informal administra-tion was filed. 2. The decedent, with date of birth April 8, 1986 and date of death December 12, 2024, was domiciled in Lincoln County, State of WI, with a mailing address of 500 S. Alexander St., Merrill, WI 54452. 3. All interested persons waived notice. 4. The deadline for filing a claim against the decedent's estate is May 16, 2025. 5. A claim may be filed at the Lincoln County Courthouse, Merrill, Wisconsin, Probate Office. Peter Delp N1080 Fairview Rd., Merrill, WI 54452 715-536-2012 Published February 6, 13 & 20, 2025 WNAXLP

BY THE COURT: DATE SIGNED: 02-11-2025 /S/Robert Russell CIRCUIT JUDGE/COURT COMMISSIONER STATE OF WISCONSIN CIRCUIT COURT, LINCOLN COUNTY Notice and Order for Name Change Hearing Case No. 25-CV-14 IN THE MATTER OF THE NAME CHANGE OF David Ronald Cook By (Petitioner) Crystel Nichol Cook By (Co-Petitioner) Devin James Callahan NOTICE IS GIVEN: A petition was filed asking to change the name of the person listed above: From: David Ronald Cook To: David Ronald Callahan Birth Certificate: David Ronald Cook IT IS ORDERED: This petition will be heard in the Circuit Court of Lincoln County, State of Wisconsin: Judge’s Name: The Honorable Robert Russell Place: Lincoln County Courthouse-Branch II, Merrill, WI 54452 Date: April 8, 2025 Time: 11:30 AM If you require reasonable accommoda-tions due to a disability to participate in the court process, please call prior to the scheduled court date. Please note that the court does not provide transportation. IT IS FURTHER ORDERED: Notice of this hearing shall be given by publication as a Class 3 notice for three (3) weeks in a row prior to the date of the hearing in the Foto News a newspaper published in Lincoln County, State of Wisconsin. Published: 2/20/25, 2/27/25 & 3/6/25 WNAXLP

BY THE COURT: DATE SIGNED: 02/03/2025 /S/HON. GALEN BAYNE-ALLISON CIRCUIT COURT JUDGE, BR I STATE OF WISCONSIN CIRCUIT COURT, LINCOLN COUNTY Notice and Order for Name Change Hearing Case No. 25-CV-12 IN THE MATTER OF THE NAME CHANGE OF Natasha Leah Becker By (Petitioner) Natasha Leah Becker NOTICE IS GIVEN: A petition was filed asking to change the name of the person listed above: From: Natasha Leah Becker To: Natasha Leah Krueger Birth Certificate: Natasha Leah Becker IT IS ORDERED: This petition will be heard in the Circuit Court of Lincoln County, State of Wisconsin: Judge’s Name: Hon. Galen Bayne-Allison Place: Lincoln County Courthouse-Br 1 1110 E. Main St., Merrill, WI 54452 Date: 03/18/2025 Time: 1:15 PM If you require reasonable accommoda-tions due to a disability to participate in the court process, please call 715-536-0319 prior to the scheduled court date. Please note that the court does not provide transportation. IT IS FURTHER ORDERED: Notice of this hearing shall be given by publication as a Class 3 notice for three (3) weeks in a row prior to the date of the hearing in the Foto News a newspaper published in Lincoln County, State of Wisconsin. Published: 2/6/25, 2/13/25 & 2/20/25 WNAXLP

BY THE COURT: DATE SIGNED: 02/17/2025 /S/HON. GALEN BAYNE-ALLISON CIRCUIT COURT JUDGE, BR I STATE OF WISCONSIN CIRCUIT COURT, LINCOLN COUNTY Notice and Order for Name Change Hearing Case No. 25-CV-17 IN THE MATTER OF THE NAME CHANGE OF Terry Ruth Sukow NOTICE IS GIVEN: A petition was filed asking to change the name of the person listed above: From: Terry Ruth Sukow To: Terri Ruth Zimmerman Birth Certificate: Terry Ruth Zimmerman IT IS ORDERED: This petition will be heard in the Circuit Court of Lincoln County, State of Wisconsin: Judge’s Name: Hon. Galen Bayne-Allison Place: Lincoln County Courthouse-Br I Courtroom 1110 E. Main St, Merrill, WI 54452 Date: 03-31-2025 Time: 10:45 AM If you require reasonable accommoda-tions due to a disability to participate in the court process, please call 715-536-0319 prior to the scheduled court date. Please note that the court does not provide transportation. IT IS FURTHER ORDERED: Notice of this hearing shall be given by publication as a Class 3 notice for three (3) weeks in a row prior to the date of the hearing in the Foto News a newspaper published in Lincoln County, State of Wisconsin. Published: 2/20/25, 2/27/25 & 3/6/25 WNAXLP

LIQUOR AND BEER LICENSE APPLICATIONS TOWN OF RUSSELL, LINCOLN COUNTY FEBRUARY 13, 2025 to JUNE 30, 2025 CLASS B BEER SLED SHED GLEASON, LLC CAMP DOERING RD, GLEASON WI 54435 Amanda Frederick, Agent Published February 20, 2025 WNAXLP

Notice is hereby given that the following application has been filed with the City Clerk, Merrill, WI: Change of Agent on Class A Beer/Class A Liquor License Beau Walker, Agent Kwik Trip # 386 2311 E Main St Merrill, WI 54452 License Period : March Council approval through current licensing period Lori Anderson-Malm City Clerk Published February 20, 2025 WNAXLP

Notice is hereby given that the following application has been filed with the City Clerk, Merrill, WI: Change of Agent on Class B Beer/Class B Liquor License Heather Pophal, Agent M&C Entertainment, LLC dba Ballyhoos 124 N Prospect St Merrill, WI 54452 License Period: April 1, 2025 through current licensing period. Lori Anderson-Malm City Clerk Published February 27, 2025 WNAXLP

NOTICE IS HEREBY GIVEN that the following has applied For a "Class B" Combination Liquor and Malt License for the M&R Tavern(formally Goodman Clubhouse) 305 Main Street, Goodman, Wisconsin for the period March 1, 2025-June 30, 2025 Mary Beth Hennen 307 Mill St Goodman, WI 54125

NOTICE OF CLAIMS DEADLINE IN THE MATTER OF THE Clifford L. and Doris N. Patz Living Trust dated March 28, 2017 Pursuant to Section 701.0508, Wis. Stats., Mark J. Patz, successor trustee of the Clifford L. and Doris N. Patz Living Trust dated March 28, 2017, with the power to pay the debts of Clifford L. Patz, date of death October 5, 2024 hereby provides notice that the deadline for filing claims for the payment of debts of Clifford L. Patz, with Mark J. Patz, as trustee of the Clifford L. and Doris N. Patz Living Trust dated March 28, 2017 is 4 months after the date of the first insertion of this Notice. Claims shall be delivered to the address set forth below. Mark J. Patz, Trustee Peter B. Harbach, Attorney Hooper Law Office, LLC 2 N. Systems Drive Appleton, WI 54914 920-993-0990 Pub 2/5, 2/12, 2/19 WNAXLP

NOTICE TO CREDITORS IN THE MATTER OF THE MYRON AND MONICA KERSCHNER LIVING TRUST DATED DECEMBER 30, 2000 PLEASE TAKE NOTICE: 1. Matthew J. Kerschner and Mark D. Kerschner are the Co-Trustees of the Myron and Monica Kerschner Living Trust dated December 30, 2000. 2. The decedent, Monica R. Kerschner, with a birth date of November 26, 1931, and date of death of November 10, 2024, was domiciled in Waushara County, State of Wisconsin, with a post office address of N2179 County Road FF, Coloma, WI 54930. 3. Deadline to make claims: All persons or companies having claims against Monica R. Kerschner and/or the Myron and Monica Kerschner Living Trust dated December 30, 2000, must present their claims to the attorney for the trustee on or before June 20, 2025*, which is four (4) months after the date of February 20, 2025, the date of first insertion and publication of this Notice in the Waushara Argus, or the claims will be forever barred as set forth in Section 701.0508 of the Wisconsin Statutes. 4. Notice of claims: Claims must be presented by delivering or mailing a written statement of the claim indicating its basis, the name and address of the claimant, the date the claim is due, the amount claimed, and describing any security for the claim. The claim is deemed presented upon receipt by the attorney for the trustee at the address set forth herein. 5. Publication of this notice shall constitute notice to any persons whose names or addresses are unknown. 6. - Attorney for trustee: Melissa S. Kampmann, Ruder Ware, L.L.S.C., P.O. Box 8050, Wausau, WI 54402-8050. #7 - 8 - 9* WNAXLP

STATE OF WISCONSIN CIRCUIT COURT BROWN COUNTY ________________________ Summit Credit Union Plaintiff v. Alexis Andres Cubillo Mendoza Defendants. Case No. 24CV1788 Code No. 30301 ________________________ PUBLICATION SUMMONS ________________________ THE STATE OF WISCONSIN To each person named above as a Defendant: YOU ARE HEREBY NOTIFIED that the Plaintiff named above has filed a lawsuit or other legal action against you. The Complaint, which is attached, states the nature and basis for the legal action. Within 40 days after February 7, 2025, of receiving this Summons, you must respond with a written Answer, as that term is used in Chapter 802 of the Wisconsin Statutes, to the Complaint. The Court may reject or disregard an Answer that does not follow the requirements of the statutes. The Answer must be sent or delivered to the Court, whose address is Clerk of Circuit Court, Brown County Courthouse, 100 S Jefferson St, PO Box 23600, Green Bay, WI 54305-3600, and to Plaintiff’s attorney, whose mailing address is PO Box 1473, Wausau, Wisconsin 54402-1473. You may have an attorney help or represent you. If you do not provide a proper Answer within 40 days after February 7, 2025, the Court may grant Judgment against you for the award of money or other legal action requested in the Complaint, and you may lose your right to object to anything that is or may be incorrect in the Complaint. A Judgment may be enforced as provided by law. A judgment awarding money may become a lien against any real estate you own now or in the future, and may also be enforced by garnishment or seizure of property. Dated this 28th day of January, 2025. Bates Legal Group, LLC, Attorney for Plaintiff By: /s/ Attorney Justin J. Bates Justin J. Bates State Bar No. 1066128 PO Box 1473 Wausau, WI 54402-1473 (715) 843-5599 Publish 02.07.25, 02.14.25 & 02.21.25 WNAXLP

STATE OF WISCONSIN CIRCUIT COURT WAUPACA COUNTY CIVIL DIVISION SERVIS ONE, INC. DBA BSI FINANCIAL SERVICES 314 S. FRANKLIN ST. TITUSVILLE, PA 16354 Plaintiff Vs. KRYSTAL M. DRAEGER N7566 NETZLER ROAD IOLA, WISCONSIN 54945 BRADEN M. PAULSON N7566 NETZLER ROAD IOLA, WISCONSIN 54945 IOLA DENTAL CLINIC S.C. C/O JAMES S. MAUS DDS, 100 PINE CREST LN., PO BOX 274 IOLA, WI 54945 PT ASSOCIATES OF PORTAGE COUNTY, INC. C/O BRYAN STUETTGEN, 2918 POST RD. STEVENS POINT, WI 54481 SECRETARY OF HOUSING AND URBAN DEVELOPMENT C/O UNITED STATES ATTORNEY, 517 E. WISCONSIN AVENUE, SUITE 530 MILWAUKEE, WI 53202 SECRETARY OF HOUSING AND URBAN DEVELOPMENT C/O ASSOCIATE GENERAL COUNSEL FOR LITIGATION, 451 7TH STREET SW WASHINGTON, DC 20410 VIA CERTIFIED MAIL SECRETARY OF HOUSING AND URBAN DEVELOPMENT C/O UNITED STATES ATTORNEY GENERAL, U.S. DEPARTMENT OF JUSTICE, 950 PENNSYLVANIA, NW WASHINGTON, DC 20530 VIA CERTIFIED MAIL Defendants PUBLICATION SUMMONS Case No. 2024CV000298 Judge Troy L. Nielsen Case Code No. 30404 THE STATE OF WISCONSIN To each person named above as Defendant: You are hereby notified that the plaintiff named above has filed a lawsuit or other legal action against you. Within 40 days after February 13, 2025, you must respond with a written demand for a copy of the complaint. The demand must be sent or delivered to the court, whose address is Yvette Kienert, Clerk of Courts, Waupaca County Courthouse, 811 Harding Street, Waupaca, WI 54981 and to Michael C. Timothy, Johnson, Blumberg & Associates, LLC, Plaintiff’s attorney, whose address is 30 N. LaSalle St., Suite 3650, Chicago, Illinois 60602. You may have an attorney help represent you. If you do not demand a copy of the complaint within 40 days, the court may grant judgment against you for the award of money or other legal action requested in the complaint, and you may lose your right to object to anything that is or may be incorrect in the complaint. A judgment may be enforced as provided by law. A judgment awarding money may become a lien against any real estate you own now or in the future, and may also be enforced by garnishment or seizure of property. Johnson, Blumberg & Associates, LLC Attorney for Plaintiff /s/ Michael C. Timothy Michael C. Timothy State Bar No. 1032915 Johnson, Blumberg & Associates, LLC 30 N. LaSalle St., Suite 3650 Chicago, Illinois 60602 Ph. 312-541-9710 Fax 312-541-9711 Dated: February 5, 2025 Pursuant to the Fair Debt Collection Practices Act (15 U.S.C. Section 1692), we are required to state that we are attempting to collect a debt on our client’s behalf and any information we obtain will be used for that purpose. Publish Feb. 13, 20 & 27, 2025 WNAXLP