The BEST Legal listings near North Central Wisconsin
The BEST Legal listings near North Central Wisconsin
Bids and Request for Proposals
ADVERTISEMENT FOR BIDS VILLAGE OF CAMPBELLSPORT CAMPBELLSPORT, WI 2024 MILL & OVERLAY PROJECT General Notice VILLAGE OF CAMPBELLSPORT is requesting Bids for the construction of the following Project: 2024 MILL & OVERLAY PROJECT Project #07792027 The Village of Campbellsport will receive and accept bids ONLY through QuestCDN.com via the online electronic bid service (QuestvBid) for the construction of 2024 Mill & Overlay Project until 10:00 am on May 2nd, 2024. All bids will be downloaded and publicly read aloud during a virtual public bid opening that will be held at the day and time of the bid closing. All plan holders will receive information via Quest on how to join the virtual meeting prior to the bid opening. The Project includes the following Work: The work for which bids are asked includes the following approximate quantities: 13,200 SY of asphalt pavement pulverizing, removal, salvaging and repaving with new asphalt binder and surface course; minor concrete curb/gutter replacement; minor removal and replacement of defective aggregate base material; traffic control; erosion control; cleanup and all related work. Obtaining the Bidding Documents Information and Bidding Documents for the Project can be found at the following designated website: www.questcdn.com Bidding Documents are available for download from QuestCDN at www.questcdn.com. You may download the digital plan documents for $45 by inputting Quest eBidDoc #9082335 on the website’s Project Search page. Please contact QuestCDN at 952-233-1632 or contact by email at info@questcdn.com for assistance in free membership registration, downloading, and working with the digital project information. Prospective Bidders are urged to register with QuestCDN as a plan holder, even if Bidding Documents are obtained from a plan room or source other than the designated website in either electronic or paper format. QuestCDN requires the bidding documents to be downloaded from the site in order to submit a bid in the Vbid system. The designated website will be updated periodically with addenda, lists of registered plan holders, reports, and other information relevant to submitting a Bid for the Project. All official notifications, addenda, and other Bidding Documents will be offered only through QuestCDN. Neither Owner nor Engineer will be responsible for Bidding Documents, including addenda, if any, obtained from sources other than QuestCDN. Instructions to Bidders. Direct all bidding inquiries to Engineer’s Project Manager, Sara Sharpe, at (920) 392-5147. No proposal will be accepted unless accompanied by a certified check or bid bond equal to at least 5% of the amount bid, payable to the Owner as a guarantee that, if the bid is accepted, the bidder will execute and file the proper contract and bond within 15 days after the award of the contract. The certified check or bid bond will be returned to the bidder as soon as the contract is signed, and if after 15 days the bidder shall fail to do so, the certified check or bid bond shall be forfeited to the Owner as liquidated damages. No bidder may withdraw their bid within 60 days after the actual date of the opening thereof. The minimum wages to be paid on the project shall be in accordance with the wage rate scale established by local wage rates. Owner reserves the right to waive any informalities or to reject any or all bids. Published by the authority of the Village of Campbellsport. CONSULTING ENGINEER: MSA Professional Services, Inc. 201 Corporate Drive Beaver Dam, WI 53916 Jason Laue, PE (920) 392-5136 4-18(2) WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Bids and Request for Proposals
classifiedsMMC.com
Legal Bids and Request for Proposals
ADVERTISEMENT FOR BIDS VILLAGE OF HORTONVILLE, WI NORTH MILL STREET RECONSTRUCTION General Notice VILLAGE OF HORTONVILLEis requesting Bids for the construction of the following Project: NORTH MILL STREET RECONSTRUCTION Project # 07807030 The Village of Hortonville will receive and accept bids ONLY through QuestCDN.com via the online electronic bid service (QuestvBid) for the construction of North Mill Street Reconstruction until April 25, 2024 at 10am. All bids will be downloaded and publicly read aloud during a virtual public bid opening that will be held at the day and time of the bid closing. All planholders will receive information via Quest on how to join the virtual meeting prior to the bid opening. The Project includes the following Work: Utility Construction: approximately 800’ of PVC water main (6”–10”) including valves, hydrants, appurtenances and services; approximately 775’ of PVC sanitary sewer (8”) including manholes and laterals; approximately 600’ of storm sewer, RCP and HDPE (12”–15”) including manholes and inlets. Roadway Construction: approximately 750’ of roadway excavation and grading, geotextile fabric, breaker run, dense graded base, hot mix asphalt, concrete & asphalt driveway replacement, concrete sidewalk and concrete curb & gutter. Tree removal, clearing, grubbing, site restoration, traffic control and erosion control are included in the project. The anticipated substantial completion date is September 27, 2024 and October 11, 2024 is Final Completion date . Obtaining the Bidding Documents Information and Bidding Documents for the Project can be found at the following designated website: www.questcdn.com Bidding Documents are available for download from QuestCDN at www.questcdn.com. You may download the digital plan documents for $45by inputting Quest eBidDoc #8914429 on the website’s Project Search page. Please contact QuestCDN at 952-233-1632 or contact by email at info@questcdn.comfor assistance in free membership registration, downloading, and working with the digital project information. Prospective Bidders are urged to register with QuestCDN as a plan holder, even if Bidding Documents are obtained from a plan room or source other than the designated website in either electronic or paper format. QuestCDN requires the bidding documents to be downloaded from the site in order to submit a bid in the Vbid system. The designated website will be updated periodically with addenda, lists of registered plan holders, reports, and other information relevant to submitting a Bid for the Project. All official notifications, addenda, and other Bidding Documents will be offered only through QuestCDN. Neither Owner nor Engineer will be responsible for Bidding Documents, including addenda, if any, obtained from sources other than QuestCDN. Instructions to Bidders. No proposal will be accepted unless accompanied by a certified check or bid bond equal to at least 5% of the amount bid, payable to the Owner as a guarantee that, if the bid is accepted, the bidder will execute and file the proper contract and bond within 15 days after the award of the contract. The certified check or bid bond will be returned to the bidder as soon as the contract is signed, and if after 15 days the bidder shall fail to do so, the certified check or bid bond shall be forfeited to the Owner as liquidated damages. No bidder may withdraw their bid within 60 days after the actual date of the opening thereof. The minimum wages to be paid on the project shall be in accordance with the wage rate scale established by local wage rates. Owner reserves the right to waive any informalities or to reject any or all bids. Published by the authority of the Village of Hortonville. CONSULTING ENGINEER: MSA Professional Services, Inc. 1500 N. Casaloma Drive Appleton, WI 54913 Dan Rammer, P.E. drammer@msa-ps.com | (920) 931-0095 Publish April 11 & 18, 2024 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Bids and Request for Proposals
classifiedsMMC.com
Legal Bids and Request for Proposals
De Pere WNAXLP SECTION 00 11 13 APRIL 12, 2024 – APRIL 19, 2024 CITY OF DE PERE ADVERTISEMENT TO BID PROJECT 24-18 MISSION SQUARE DUMPSTER ENCLOSURE CONSTRUCTION Online bids will be received and accepted for Project 24-18 Mission Square Dumpster Enclosure Construction via the online electronic bidding service through QuestCDN.com, until 1:00 PM, Thursday, May 2, 2024, at which time they will be publicly accepted, displayed and read aloud. Project 24-18 for which proposals are being sought includes the following approximate quantities: • One (1) dumpster enclosures with the following quantities: o An 18-foot by 26-foot by eight-inch concrete slab with an integral 12-inch by 12-inch footing and two #4 bars continuous at the perimeter for the enclosure wall to sit atop. Concrete slab is to have an eight-inch to 12-inch crushed aggregate base. o 40 feet of enclosure wall constructed of an eight-inch split faced concrete masonry unit wall. Masonry unit wall shall be constructed with four-foot #4 bars at 24-inches on center extending a half-foot into the concrete slab. o Two (2) enclosure gates. o Three (3) six-inch diameter concrete filled galvanized steel pipes (field painted) set in 18-inch diameter concrete footing extending four feet below grade. o One (1) four-foot wide, hinge mounted access door. • 15-inch crushed aggregate base restoration. Complete digital project bidding documents are available for viewing and/or downloading at www.QuestCDN.com or may be examined at the office of the Director of Public Works. Digital plan documents may be downloaded for $22 by inputting Quest project #9062319 on Quest’s Project Search page. Project documents must be downloaded from QuestCDN which will add your company to the Planholder List and allow access to vBid online bidding for the submittal of your bid. Bidders will be charged an additional fee of $42 to submit a bid electronically. The QuestCDN website can also be accessed through the City website at www.deperewi.gov/projects or by pressing the Projects icon at the bottom of any City website page. Contact QuestCDN Customer Support at 952-233-1632 or info@questcdn.com for assistance in membership registration, downloading digital project information and vBid online bid submittal questions. Each proposal shall be accompanied by a bid bond in an amount equal to five percent (5%) of the bid, payable to the City of De Pere, as a guarantee that if the bid is accepted, the bidder will execute a contract and furnish a contract bond as set forth in the General Conditions of the City of De Pere. In case the bidder fails to file such contract and bond, the amount of the bid bond shall be forfeited to the City of De Pere as liquidated damages. The letting of the contract is subject to the provisions of the following Wisconsin Statutes: Section 62.15 regarding Public Works. Section 66.0901(3) regarding Prequalification of Contractor. Each bidder shall pre-qualify by submitting proof of responsibility on forms furnished by the Director of Public Works. Such forms shall be filed with the Director of Public Works no later than 4:00 PM, Monday, April 29, 2024. Prospective bidders who have previously submitted such forms subsequent to January 1, 2024will not be required to separately submit such forms for this project. The City of De Pere reserves the right to reject any or all bids, to waive any informalities in bidding and to accept any proposal which the Common Council deems most favorable to the interest of the City of De Pere. Dated this 12th day of April 2024. Board of Public Works City of De Pere Eric Rakers, P.E. City Engineer Project 24-18 Publish 04.12.24 & 04.19.24 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Bids and Request for Proposals
classifiedsMMC.com
Legal Bids and Request for Proposals
Green Bay WNAXLP NOTICE TO CONTRACTORS Contract: “ CD24-01 FARLIN PARK SITE REDEVELOPMENT PHASE I” City of Green Bay, Wisconsin Proposals will be received and accepted ONLY through QuestCDN.com via their electronic VirtuBid™ (vBid) online bid service until 2:00 p.m. on Tuesday, April 23, 2024 at which time they will be opened privately for Public Works Improvement Contract: “CD24-01 FARLIN PARK SITE REDEVELOPMENT PHASE I” in accordance with the plans therefore, the City of Green Bay Standard Specifications and Construction Standards for Public Works Construction, 2024 Edition, and the special provisions of this contract, all of which are on file in the City Clerk's/Treasurer's Office and the Director of Public Works Office in the Green Bay City Hall. The work under this contract shall consist of the clearing and grubbing of trees, stripping topsoil within the constructions limits; sub grading of the site and installation of a bio-retention pond. The project will extend water service into the site, extend electrical services from an existing restroom nbuilding, construct a concrete plaza area with a shelter, construct a utility shed, install splashpad/fog system equipment, install benches, and construct a basketball court. The Contract Documents, including plans and specifications, may be examined electronically at www.questcdn.com and downloaded for a fee of $42.00. Prospective bidders must register with QuestCDN in order to download documents which will add your company to the Planholder List and allow access to vBid online bidding for the submittal of your bid which is required for this project. The charges for bidding documents are non-refundable. Contact QuestCDN Customer Support at 952-233-1632 or info@questcdn.com for assistance in membership registration, downloading digital project information and vBid online bid submittal. The work shall be let in accordance with the following Sections of the Wisconsin Statutes. 1. Section 62.15 regarding public works construction. 2. Section 779.15 regarding lien on contractors. 3. Section 66.0901(2) regarding proof of responsibility. All bidders shall provide proof of responsibility on the form furnished by the Director of Public Works and it shall be filed with the Director of Public Works not less than five (5) days prior to the time set for opening of bids. Said proof of responsibility shall not be valid if filed prior to one year of the date of opening bids. In accordance with Section 42-2 of the City of Green Bay Code of Ordinances, any corporation, firm, or individual violating Chapter 133.01 of the Wisconsin Statutes, or any subsequent amendment thereof, shall upon conviction thereof be thereby disqualified as a bidder on any City of Green Bay project for a period of three (3) years from the date of such conviction; however, nothing herein shall be interpreted to preclude such corporation, firm, or individual from completing any and all contracts he/she may already have with the City at the time of such conviction, nor shall this ordinance be applied retroactively to convictions occurring prior to the adoption and publication of this ordinance. This prohibition applies with like force to officers of convicted corporations, firms, or individuals who thereafter have business interest in new corporations or business enterprises of whatever kind or description. The City of Green Bay, Wisconsin reserves the right to reject any or all bids and to waive any informality in bidding. No bids shall be withdrawn after the opening of bids without the consent of the City of Green Bay,Wisconsin for a period of sixty (60) days after the scheduled time for closing bids. All proposals must be submitted through QuestCDN.com via their electronic vBid online bid service provided for that purpose and issued to the specific bidder by the Director of Public Works together a bid bond equal to at least five (5) but not more than ten (10) percent of the bid payable to the City of Green Bay as a guarantee that if his/her bid is accepted, he/she will execute and file the contract and a performance bond in the amount of one hundred percent (100%) of the total bid within ten (10) days after the award of the contract. Only the Proposal Pages, Bid Bond, Affidavit of Compliance, Disclosure of Ownership and any Addenda issued shall be submitted. Only Proposals submitted by firms appearing on the City of Green Bay list of plan holders will be opened. In case the successful bidder shall fail to execute such Contract and Performance Bond, the amount of the check or bid bonds shall be forfeited to the Redevelopment Authority as liquidated damages. Attention is called to the fact that not less than the minimum salaries and wages, as set forth in the Contract Documents, must be paid in the performance of this work, and that the work covered by this proposal is on a project assisted under a program providing direct Federal financing assistance from the U.S. Department of Housing & Urban Development and is subject to all applicable provisions of the Housing and Community Development Act of 1974, and Section 3 of the Housing and Urban Development Act of 1968, as amended, 12 U.S.C.1701u. The Contractor shall give each subcontractor a copy of the “Prevailing Wage Rate Determination” contained in the Contract Documents prior to submittal of the bid. If a copy of the “Prevailing Wage Determination” has not been provided by the Contractor or additional copies are needed, copies can be obtained from the Office of the Redevelopment Authority, Room 608, City Hall, 100 North Jefferson Street, Green Bay, Wisconsin 54301. The bidder's attention is called to the "Notice of Requirements for Affirmative Action to Insure Equal Employment Opportunity (Executive Order No. 11246)" contained in the Contract Documents, which set forth, in part, goals and timetables for the employment of women and minorities in the project area. The bidder's attention is called to the "Restrictions on Public Buildings and Public Works Projects Certification" contained in the Contract Documents, which sets forth restrictions for contractors affiliated with foreign countries on the list of countries that discriminate against U.S. firms. The Redevelopment Authority of the City of Green Bay, Wisconsin, reserves the right to reject any or all bids or to waive any informalities in the bidding. Bids may be held by the Redevelopment Authority of the City of Green Bay, Wisconsin, for a period not to exceed sixty (60) days from the date of the opening for purposes of reviewing the bids and investigating the qualifications of bidders prior to awarding of the Contract. REDEVELOPMENT AUTHORITY OF THE CITY OF GREEN BAY, WISCONSIN By: Gary Delveaux, Chairman Advertised: April 5, 2024 April 12, 2024 WNAXLP
You must Register or Login before you can email ad listings
Listed: Wed Apr 10th
classifiedsMMC.com
Legal Bids and Request for Proposals
classifiedsMMC.com
Legal Bids and Request for Proposals
Green Bay WNAXLP NOTICE TO CONTRACTORS Contract: “BRIDGE 2-24 PAINTING (B-5-141, B-5-154, B-5-275)” City of Green Bay, Wisconsin Proposals will be received and accepted ONLY through QuestCDN.com via their electronic VirtuBid™ (vBid) online bid service until 2:00 p.m. on Tuesday, May 5, 2024 , at which time they will be opened for Public Works Improvement Contract: “BRIDGE 2-24 PAINTING (B-5-141, B-5-154, B-5-275)” in accordance with the plans therefore, the City of Green Bay Standard Specifications and Construction Standards for Public Works Construction, 2024 Edition, and the special provisions of this contract, all of which are on file in the City Clerk's/Treasurer's Office and the Director of Public Works Office in the Green Bay City Hall. The work on this contract will consist of preparing structural steel for painting and application of a three-part paint system including collection and containment of waste materials. The work performed under this Contract includes furnishing all the material, labor, tools, equipment, services, methods, skills, and supervision necessary to satisfactorily complete the work. The work on this Contract will take place at B-5-141 Main Street over East River, B-5-154 E Mason Street over East River, and B-5-275 Baird Street over East River. The Contract Documents, including plans and specifications, may be examined electronically at www.questcdn.com and downloaded for a fee of $42.00. Prospective bidders must register with QuestCDN in order to download documents which will add your company to the Planholder List and allow access to vBid online bidding for the submittal of your bid which is required for this project. The charges for bidding documents are non-refundable. Contact QuestCDN Customer Support at 952-233-1632 or info@questcdn.com for assistance in membership registration, downloading digital project information and vBid online bid submittal. The work shall be let in accordance with the following Sections of the Wisconsin Statutes. 1. Section 62.15 regarding public works construction. 2. Section 779.15 regarding lien on contractors. 3. Section 66.0901(2) regarding proof of responsibility. All bidders shall provide proof of responsibility on the form furnished by the Director of Public Works and it shall be filed with the Director of Public Works not less than five (5) days prior to the time set for opening of bids. Said proof of responsibility shall not be valid if filed prior to one year of the date of opening bids. In accordance with Section 42-2 of the City of Green Bay Code of Ordinances, any corporation, firm, or individual violating Chapter 133.01 of the Wisconsin Statutes, or any subsequent amendment thereof, shall upon conviction thereof be thereby disqualified as a bidder on any City of Green Bay project for a period of three (3) years from the date of such conviction; however, nothing herein shall be interpreted to preclude such corporation, firm, or individual from completing any and all contracts he/she may already have with the City at the time of such conviction, nor shall this ordinance be applied retroactively to convictions occurring prior to the adoption and publication of this ordinance. This prohibition applies with like force to officers of convicted corporations, firms, or individuals who thereafter have business interest in new corporations or business enterprises of whatever kind or description. The City of Green Bay, Wisconsin reserves the right to reject any or all bids and to waive any informality in bidding. No bids shall be withdrawn after the opening of bids without the consent of the City of Green Bay, Wisconsin for a period of sixty (60) days after the scheduled time for closing bids. All proposals must be submitted through QuestCDN.com via their electronic vBid online bid service provided for that purpose and issued to the specific bidder by the Director of Public Works together a bid bond equal to at least five (5) but not more than ten (10) percent of the bid payable to the City of Green Bay as a guarantee that if his/her bid is accepted, he/she will execute and file the contract and a performance bond in the amount of one hundred percent (100%) of the total bid within ten (10) days after the award of the contract. Only the Proposal Pages, Surety Bond, Affidavit of Compliance, Disclosure of Ownership and any Addenda issued shall be submitted. Only Proposals submitted by firms appearing on the City of Green Bay list of plan holders will be opened. In case the successful bidder shall fail to execute such contract and performance bond, the amount of the check or bid bond shall be forfeited to the City as liquidated damages. Published by the authority of the Improvement & Services Committee of the Common Council of the City of Green Bay, Wisconsin. BY: Mark Steuer, Chairperson Advertised: April 12, 2024 April 19, 2024 April 26, 2024 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Bids and Request for Proposals
classifiedsMMC.com
Legal Bids and Request for Proposals
Howard WNAXLP SECTION 00020 ADVERTISEMENT FOR BIDS Village of Howard 1336 Cornell Road Green Bay, WI 54313-8923 Sealed bids for the Nature Court Sanitary Sewer Extension will be received by the Village of Howard at the Public Works Facility, 1336 Cornell Road, Green Bay, WI 54313-8923, until April 23, 2024 , at 1:30 P.M., CT, and shall include the following approximate quantities: 2640 L.F. - Sanitary Sewer 400 Tons - Asphaltic Pavement 150 L.F. - Bore & Jack Steel Casing 5000 Tons - Crushed Aggregate 130 L.F. - Directional Drill Sewer 2500 C.Y. - Excavation The project is scheduled to be completed by September, 2024. Bids will be publicly opened and read aloud. The Bidding Documents, consisting of Advertisement for Bids, Instructions to Bidders, General Conditions, Supplementary Conditions, Bid Bond, Agreement, Payment and Performance Bonds, Notice of Award, Notice to Proceed, Addenda, Certificate of Substantial Completion, and Drawings and Specifications, may be examined at the following locations: Issuing Office: Village of Howard Public Works Facility 1336 Cornell Road Green Bay, WI 54313 (920)434-4060 Bidding and the award of work will be in accordance with the provisions of Section 61.55 and 66.0901. Each proposal must be accompanied by a Bid bond or certified check equivalent to 5% of the maximum proposal. The Owner reserves the right to reject any or all bids, waive or not waive any informalities in the bids received, and to accept any proposal, which they deem most favorable to the interest of the Owner. No bidder may withdraw his bid within 150 days after the actual date of the opening thereof. Complete digital project bidding documents are available at www.questcdn.com . Bidders shall download the digital plan documents for $30.00 by inputting Quest project #9062352 on the website’s Project Search. Please contact QuestCND.com at 952-233-1632 or info@questcdn.com for assistance in free membership registration, downloading, and working with this digital project information. No paper plan sets will be provided. Please contact us at(920)434-4060 if you have any questions. Josh Gerrits, P.E. Village Engineer Publication Date: 04/05/24 Publication Date: 04/12/24 WNAXLP
You must Register or Login before you can email ad listings
Listed: Wed Apr 10th
classifiedsMMC.com
Legal Bids and Request for Proposals
classifiedsMMC.com
Legal Bids and Request for Proposals
SECTION 00 11 13.00 ADVERTISEMENT FOR BIDS CITY OF WEYAUWEGA Waupaca County, Wisconsin OWNER - The City of Weyauwega, acting through its Common Council, hereby gives notice that Online Bids will be received in the City Hall for the following described project. PROJECT The work shall consist of construction of replacement of approximately 10 lead water service laterals (public and private) including associated curb stops and connection to the main. Work shall include restoration. Davis Bacon Wage Rates, Buy America Build America and DBE/WBE/MBE compliance is required since SDWLP Funds are being used for the project. Bids will be received on the following Contract: Contract No. W0086-09-23-00427 2024 LEAD SERVICE REPLACEMENT TIME – Online Bids will be received until 2:00 p.m., local time, on May 2, 2024, in the Weyauwega City Hall, 109 E. Main Street, Weyauwega, WI 54983, at which time and place all Bids will be viewed online via QuestCDN.com. BIDS All Bids shall be submitted online via QuestCDN eBidDoc™. All Bidders shall Bid in accord¬ance with and upon the Bid Forms included in the Contract Documents. EXAMINATION OF BIDDING DOCUMENTS The Project Documents are on file for inspection at the offices of McMahon Associates, Inc., 1445 McMahon Drive, Neenah, Wisconsin 54956. PROCUREMENT OF BIDDING DOCUMENTS In order to be a ‘Plan Holder’ or ‘Bidder’, each firm or organization shall either download Bidding Documents from the McMahon Associates, Inc. website ( www.mcmgrp.com ) utilizing QuestCDN eBidDocTM or by obtaining a hard copy as designated in this Advertisement For Bids. Complete digital Bidding Documents are available at www.mcmgrp.com or www.questcdn.com . Digital Bidding Documents may be downloaded for a non-refundable $40.00 by inputting Quest Project No. 9082343 on the website’s Project Search page. On-line bid submission is required for this project for a non-refundable $55.00. Contact QuestCDN.com at 952-233-1632 or info@questcdn.com for assistance in free membership registration, downloading, and working with this digital project information. An optional ‘paper’ set of Bidding Documents is also available for a non-refundable $60.00 (approximate cost) plus applicable sales tax and shipping. Contact Blue Print Service Company for more information on paper Bidding Documents and payment options available. Full-size Drawings are available upon request at an additional cost. Neither the Owner nor McMahon Associates, Inc. shall be held responsible for the scale of downloaded Drawings. Printed Drawings obtained from Blue Print Service Company shall be considered to be scalable. Blue Print Service Company 2350 West Pershing Street; Suite A Appleton, WI 54914 920-733-4539 - Telephone 920-733-1438 - Fax bps@blueprintservice.com - Email Blue Print Service Company 2201 South Oneida Street, Suite 8 Green Bay, WI 54304 920-494-4539 - Telephone 920-494-4551 - Fax bps@blueprintservice.com - Email BID SECURITY No Bid shall be received unless accompanied by a Certified Check or satisfactory Bid Bond payable to the City of Weyauwega in an amount not less than 10% of the maximum Bid as a guaran¬tee that, if the Bid is accepted, the Bidder will execute and file the Contract, Performance/Payment Bonds and Insurance Certifica¬tion, as required by the Contract Documents, within 15-days after the Notice of Award. BID REJECTION The OWNER reserves the right to reject any and all Bids, waive any informalities in Bidding or to accept the Bid or Bids which best serves the interests of the City of Weyauwega. WITHDRAWAL OF BIDS No Bid shall be withdrawn for a period of 30-days after the scheduled opening without the consent of the OWNER. PROOF OF RESPONSIBILITY A Proof Of Responsibility (Pre-Qualification) Form for all Contracts in excess of $10,000 must be filed in the office of the City of Weyauwega not later than five (5) calendar days prior to the date of receiving Bids, and shall show sufficient ability, equipment and experience to properly perform the Contract. The City of Weyauwega's decision as to qualifications shall be final. GOVERNING LAWS & REGULATIONS The Contract letting shall be subject to the provisions of Sections 66.0901, 66.0903 and 779.14 of the Wisconsin Statutes. WAGE RATE DETERMINATIONS - The CONTRACTOR shall be required to pay not less than the Wage Rates established for the project by the U.S. Department Of Labor - Davis-Bacon, and pay wages at rates not less than the highest rate noted for each trade. Copies of the applicable Wage Rates are on file with the OWNER and/or incorporated in the Contract Documents. WISCONSIN SAFE DRINKING WATER LOAN PROGRAM - Any Contract or Contracts awarded under this Advertisement For Bids are expected to be funded in part from the Wisconsin Safe Drinking Water (SDW) Loan Program. This procurement will be subject to regulations contained in NR.166, Wisconsin Adminis¬tra¬tive Code and appropriate State Statues. This project has been designated a Federal Equivalency project. DISADVANTAGED BUSINESS ENTERPRISES - The City of Weyauwega (OWNER) encourages Disadvantaged Business Enterprises (DBE), including Minority-Owned Businesses (MBE) and Women-Owned Businesses (WBE), to submit Bids. Any Contract or Contracts awarded under this Advertisement For Bids shall demonstrate positive efforts to utilize Minority-Owned and Women-Owned Businesses. This procurement will be subject to regulations contained in NR.166. BUILD AMERICA, BUY AMERICA ACT (BABA) - It shall be mandatory for the CONTRACTOR(s), including any Subcontractor, to comply with all requirements of Federal HR 3684, ‘Infrastructure Investment and Jobs Act’, specifically Division G, Title IX, as it pertains to the use of Build America, Buy America. Published by the authority of the City of Weyauwega, acting through its Common Council. CITY OF WEYAUWEGA | Waupaca County, Wisconsin Publish Thursday, April 18, 2024 Thursday, April 25, 2024 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Bids and Request for Proposals
classifiedsMMC.com
Legal Bids and Request for Proposals
Town of Bear Creek Request for Bids The Town of Bear Creek is requesting sealed bid for mowing of town ditches. The Town has 40 miles of town roads. For additional information, contact Theresa Huss at (715) 701-4992. Bids will be accepted until 7:00pm on May 12th by the Clerk. The Town of Bear Creek reserves the right to accept or reject any and all bids and to accept the bid in the best interest of the town. Town of Bear Creek, Clerk E9397 Bear Creek Rd. Clintonville, WI 54929 Publish April 18 & 25, 2024 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Bids and Request for Proposals
classifiedsMMC.com
Legal Bids and Request for Proposals
Town of Osborn NOTICE Advertisement for Bids Notice is hereby given by the Town of Osborn, Outagamie County, Wisconsin, that it will receive bids until 5:00 pm on the 13th day of May, 2024. Sealed Bids can be mailed to Darlene Schultz, Clerk at the Town of Osborn, N6362 Ballard Road, Seymour, WI 54165. Bids will be publicly opened and read on May 13th, 2024 at 6:30 pm, Osborn Town Hall, W3389 Cnty Rd EE, Seymour, WI. Town specs require MS5 Hot Oil liquid asphalt and & 100% fractured 1/8” granite black stone with cold mix patching/leveling as needed. The road projects are Mielke Rd (French Rd to C .94 miles), French Rd (Culbertson Rd to Hwy 54 .92 miles) and Sievert Rd to J 1.01 miles). For more specifications, contact Dennis Hoffman at 920-450-4548. The town reserves the right to accept or reject any or all bids. Publish April 15 & 22, 2024 WNAXLP
You must Register or Login before you can email ad listings
Listed: Mon Apr 8th
classifiedsMMC.com
Legal Bids and Request for Proposals
classifiedsMMC.com
Legal Bids and Request for Proposals
Election Notices
TOWN OF AUBURN PUBLIC TEST NOTICE IS HEREBY GIVEN that the public test of the Dominion ICE Voting Equipment to be used at the Election on April 2, 2024 will be conducted at the Auburn Town Hall, W1728 Sunset Drive, Campbellsport, Wisconsin at 3:00 p.m. on March 27, 2024. This public test is open to the general public, Chapter 5, Sec. 5.84 Wisconsin Statues. Bonnie Berg, CMC Town Clerk 3/21 WNAXLP
You must Register or Login before you can email ad listings
Listed: Wed Mar 20th
classifiedsMMC.com
Legal Election Notices
classifiedsMMC.com
Legal Election Notices
VOTING BY ABSENTEE BALLOT Any qualified elector who is unable or unwilling to appear at the polling place on Election Day may submit a request to vote an absentee ballot to their municipal clerk. A qualified elector is any U.S. citizen, who will be 18 years of age or older on Election Day, who has resided in the ward or municipality where he or she wishes to vote for at least 28 consecutive days before the election. The elector must also be registered in order to receive an absentee ballot. Proof of identification must be provided before an absentee ballot may be issued. You must make a request for an absentee ballot in writing or online at MyVote.wi.gov. Contact your municipal clerk and request that an application for an absentee ballot be sent to you for the primary or election or both. You may also submit a written request in the form of a letter, or you may apply for an absentee ballot online at MyVote.wi.gov. Your written request must list your voting address within the municipality where you wish to vote, the address where the absentee ballot should be sent, if different, and your signature. You may make application to your municipal clerk for an absentee ballot in person, by mail, by fax, by email or at MyVote.wi.gov. Making application to receive an absentee ballot by mail The deadline for making application to receive an absentee ballot by mail is: March 29th, 2024 @ 5:00 p.m. Note: Special absentee voting application provisions apply to electors who are indefinitely confined to home or a care facility, in the military, hospitalized, or serving as a sequestered juror. If this applies to you, contact the municipal clerk regarding deadlines for requesting and submitting an absentee ballot. Voting an absentee ballot in person You may also request and vote an absentee ballot in the clerk's office or other specified location during the days and hours specified for casting an absentee ballot in person. Village of Iola Ph: (715) 445-2913 • 180 S. Main St., Iola, WI 54945 The first day to vote an absentee ballot in the clerk’s office is / was: Dates & Hours: (no appointments needed) Monday – Friday Beginning March 19th, 2024, thru March 29th, 2024; Hours: 8:00 A.M. to 1:00 P.M. Appointments needed: for: Weekends or Daily Non-Business Hours the dates of March 19th thru March 29th, 2024. Please call the clerk's office at (715) 445-2913 to schedule a time. The last day to vote an absentee ballot in the clerk's office: March 29th, 2024 @ 5:00 p.m. without an appointment No in-person absentee voting may occur on the day before the election. The municipal clerk will deliver voted ballots returned on or before Election Day to the proper polling place or counting location before the polls close on April 2nd, 2024. Any ballots received after the polls close will not be counted. Publish March 21, 2024 WNAXLP
You must Register or Login before you can email ad listings
Listed: Tue Mar 26th
classifiedsMMC.com
Legal Election Notices
classifiedsMMC.com
Legal Election Notices
Legals
“NOTICE” TRI-LAKES MANAGEMENT DISTRICT SPECIAL MEETING Pursuant to Sec. 33.305(4) Wisconsin State Statutes And the By-Laws of the Tri-Lakes Management District The Meeting will be held at 1555 Apache Avenue, Rome, WI Saturday, May 4th, 2024 from 8:00 A.M. until 4:00 PM The Tr-Lakes Management District will hold a special meeting on Saturday, May 4th . The meeting will be open from 8:00 AM until 4:00 PM for the Tri-Lakes Management District Electors to cast their ballots anytime during this time frame. The vote will ask electors to authorize the Tri-Lakes Board to secure a loan for the Nano- Bubble project. A second vote will allow the Tri-Lakes board to secure a bond to cover the loan proceeds and future costs for the Nano-Bubble project. These 2 items will be discussed at length at the 3 meetings along with the details of the project. No absentee ballots or proxies are permitted at a special meeting.
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals
Allouez WNAXLP ATTENTION ALLOUEZ RESIDENTS The Water Department will be Flushing Dead-End Water Mains throughout the entire Village April 22nd – May 10th PLEASE CHECK TAP WATER FOR DISCOLORATION BEFORE USING Carrie Zittlow Clerk/Treasurer Village of Allouez Publish 04.19.24 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals
Ashwaubenon WNAXLP RETAIL ALCOHOL LICENSE Notice is hereby given that the following application has been received by the Clerk of the Village of Ashwaubenon: Reserve Class “B” Beer/”Class B” Liquor License – MC Ashwaubenon, Inc. dba Millions Crab, 2800 S Oneida Street, (Sze Yin Commi Tong, agent). /s/ Kris A. Teske, Village Clerk (RUN): April 19, 2024 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals
BY THE COURT DATE SIGNED: March 28, 2024 Electronically signed by Becky S. Byer Probate Registrar STATE OF WISCONSIN, CIRCUIT COURT, LINCOLN COUNTY IN THE MATTER OF THE ESTATE OF James H. Von Loh Notice to Creditors (Informal Administration) Case No. 2024 IN 16 PLEASE TAKE NOTICE: 1. An application for informal administra-tion was filed. 2. The decedent, with date of birth 10-29-1952 and date of death 2-4-2024, was domiciled in Lincoln County, State of Wisconsin, with a mailing address of W3964 Center Rd, Merrill, WI 54452. 3. All interested persons waived notice. 4. The deadline for filing a claim against the decedent's estate is 07-19-2024. 5. A claim may be filed at the Lincoln County Courthouse, Merrill, Wisconsin, Probate Office. Robert Von Loh N2092 Highridge Rd, Merrill WI 54452 715-921-2372 Published April 4, 11 & 18, 2024 WNAXLP
You must Register or Login before you can email ad listings
Listed: Tue Apr 16th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals
BY THE COURT: DATE SIGNED: 04/02/2024 /S/HON. GALEN BAYNE-ALLISON CIRCUIT COURT JUDGE, BR I STATE OF WISCONSIN CIRCUIT COURT, LINCOLN COUNTY Notice and Order for Name Change Hearing Case No. 24-CV-49 IN THE MATTER OF THE NAME CHANGE OF Anne Marie Shrigley By (Petitioner) Anne Marie Shrigley NOTICE IS GIVEN: A petition was filed asking to change the name of the person listed above: From: Anne Marie Shrigley To: Adrian Jaimie Shrigley Birth Certificate: Anne Marie Shrigley IT IS ORDERED: This petition will be heard in the Circuit Court of Lincoln County, State of Wisconsin: Judge’s Name: Hon. Galen Bayne-Allison Place: Lincoln County Courthouse-Br I Corutroom 1110 E. Main St., Merrill, WI 54452 Date: May 8, 2024 Time: 10:00 AM If you require reasonable accommoda-tions due to a disability to participate in the court process, please call 715-536-0319 prior to the scheduled court date. Please note that the court does not provide transportation. IT IS FURTHER ORDERED: Notice of this hearing shall be given by publication as a Class 3 notice for three (3) weeks in a row prior to the date of the hearing in the Foto News a newspaper published in Lincoln County, State of Wisconsin. Published: 4/18/24, 4/25/24 & 5/2/24 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals
CITY OF MERRILL 1004 EAST FIRST STREET MERRILL, WI 54452 NOTICE OF PUBLIC HEARINGS All persons interested will be given an opportunity to be heard at a public hearing to be held by and before the Zoning Board of Appeals of the City of Merrill, Wisconsin, commencing at 6:00 p.m. on Monday, May 13, 2024, in the Council Chambers, City Hall, 1004 East First Street, Merrill, Wisconsin, on the following proposed matters, to wit; 1.) Mark Scott, 607 N Cleveland Street, requesting a variance to M.M.C. Sec 113-317, lot coverage for an accessory building in a Residential District. Legally described in PIN# 251-3106-122-0034. Anyone having any questions regarding the hearing should contact Zoning Administrator, Darin Pagel at 536-4880. Dated: April 15, 2024 CITY OF MERRILL, WISCONSIN By: Lori Anderson-Malm City Clerk Published April 25, 2024 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals
CITY OF MERRILL COMMON COUNCIL TUESDAY, APRIL 9, 2024 MINUTES REGULAR MEETING CITY HALL COUNCIL CHAMBERS 7:00 PM I. Call to Order Mayor Hass called the meeting to order at 7:00 PM. II. Invocation - Pastor Mike Southcomb - St Stephens UCC III. Pledge of Allegiance IV. Roll Call Present: Alderperson Russell, Alderperson Caylor, Alderperson Meyer, Alderperson Fermanich, Alderperson Lupton, Alderperson Rick, Alderperson Weix Jr., Alderperson Sabatke Others present: Mayor Hass, City Attorney Hayden, City Clerk Anderson-Malm, City Administrator Akey, Building Inspector/Zoning Administrator Pagel, Enrichment Center Director Mrachek (remote), Finance Director Ley, Fire Chief Klug, Police Chief Bennett, Street Superintendent Bonack, Transit Director Brummond (remote), Utility Operations Manager Steinagel, Alderperson elect Lass, Alderperson elect Andrew Caylor, Alderperson elect Rutkowski, Pastor Mike Southcomb, Clyde Nelson, Gary and Mary Schwartz, Sue Kunkel, Gary Latzig, and Merrill Community Media. V. Common Council Meeting Expectations VI. Public Comment There was no public comment. VII. Proclamation 1. 2024 Mayoral Proclamation: Provider Appreciation Day - City Attorney Hayden read the proclamation. VIII. Revenue and Expense Reports 1. March Revenue and Expense Reports - Alderperson Meyer motioned to approve the March Revenue and Expense reports. Alderperson Fermanich seconded and the motion passed. 2. Revised February Revenue and Expense Reports - Alderperson Meyer motioned to approve the revised February Revenue and Expense reports. Alderperson Fermanich seconded and the motion Passed. IX. Minutes from Previous Meeting 1. Consider placing the minutes from the March 12th meeting on file - Alderperson Caylor motioned to place the March 12th minutes on file. Alderperson Weix Jr. seconded and the motion passed. X. Communications and Petitions 1. Insurance claim from State Auto on behalf of Lynn Kleinschmidt, regarding a slip and fall claim (December 15, 2022). The City's insurance carrier recommends this claim be disallowed. This is based on the fact that an investigation revealed the City was not liable for this incident. - Alderperson Rick motioned to disallow the 2022 claim. Alderperson Russell seconded and the motion passed. XI. General Agenda Items for Consideration 1. Consider the 2024-2025 Merrill Police Union contract. Mayor Hass is bringing this directly to the Common Council. - Alderperson Lupton motioned to approve. Alderperson Weix Jr. seconded and the motion passed. XII. Committee of the Whole 1. Take any action regarding the remaining unallocated ARPA funds of $9,999.76 from the earlier Committee of the Whole. - City Clerk Anderson-Malm read the actions from the earlier Committee of the Whole. Motion to use unallocated ARPA funds for the Food Truck-a-palooza and future Food Truck-a-palooza events. Alderperson Meyer motioned to approve the motion from the Committee of the Whole. Alderperson Sabatke seconded and the motion passed on a 7/1 voice vote. 2. Take any action regarding the EV Charging Station placement and possible funding source from the earlier Committee of the Whole. - City Clerk Anderson-Malm read the motion from the earlier Committee of the Whole; motion to table the EV charging stations, which passed on a 7/1 voice vote. City Attorney Hayden stated no further action is necessary considering the item was tabled. XIII. Board of Public Works 1. Discuss and consider the updated 2024 Street Opening permit and fees. The Board of Public Works recommends approval. - Alderperson Sabatke motioned to approve. Alderperson Meyer seconded and the motion passed. 2. Consider the bid for the M2024-02 paving project (S Center Avenue and N Sales St) to American Asphalt of Wisconsin Division of Mathy for $517,380.50. The Board of Public Works recommends approval. - Alderperson Sabatke motioned to approve. Alderperson Rick seconded and the motion passed. 3. Consider the paving budget of $7,400 to pave the north side of the alley by Our Savior's Church. The Board of Public Works recommends approval. - Alderperson Meyer motioned to approve. Alderperson Lupton seconded and the motion passed. XIV. Health & Safety 1. Consider a temporary Class "B" picnic license for the Merrill Historical Society, on April 27, 2024, at The Cosmo Hall, 805 E Main Street, in conjunction with the Merrill Historical Society Trivia Contest 2024. The Health & Safety Committee recommends approval. - Alderperson Lupton motioned to approve. Alderperson Weix Jr. seconded and the motion passed. 2. Consider a temporary Class "B" picnic license for the Lincoln County Fair Association, on August 7, 8, 9, 10, and 11, 2024 at the Merrill Festival Grounds in conjunction with the Lincoln County Fair. The Health & Safety Committee recommends approval. - Alderperson Rick motioned to approve. Alderperson Caylor seconded and the motion passed. Alderperson Meyer abstained. 3. Consider a Class A liquor license for Makalu Real Estate LLC, 1201 Grand Avenue. The Health & Safety Committee recommends approval. - Alderperson Lupton motioned to approve. Alderperson Weix Jr. seconded and the motion passed. 4. Consider a Class "A" liquor license for Merrill Petroleum LLC, 3350 E Main Street. The Health & Safety Committee recommends approval. - Alderperson Caylor motioned to approve. Alderperson Meyer seconded and the motion passed. 5. Consider a Class A liquor license for Express Lane (CAPL Retail LLC), 702 N Center Avenue. The Health & Safety Committee recommends approval. - Alderperson Rick motioned to approve. Alderperson Weix Jr. seconded and the motion passed. XV. Personnel & Finance 1. Consider implementing a hiring freeze, except for Police and Fire line positions; have vacant positions evaluated by the Personnel & Finance Committee and forwarded to the Common Council with the Mayor having the ability to bring a position directly to the Common Council. The Personnel & Finance Committee recommends approval. It was suggested by the Administration to include Transit personnel in the final action. - Alderperson Caylor motioned to amend the original motion to include Transit personnel. Alderperson Meyer seconded and the motion passed. 2. Consider the elimination of the Community Development Program Director position upon the retirement of the current employee, effective May 1, 2024. The Personnel & Finance Committee recommends approval. - Following discussion, which included Alderperson Caylor thanking the Community Development Program Director for her service over the past 27 years and Building Inspector/Zoning Administrator Pagel thanking the CDPD publically. Alderperson Russell motioned to approve. Alderperson Meyer seconded, and the motion passed on a 7/1 voice vote. XVI. Tourism Commission 1. Tourism Report - 2023 - Executive Director of the Chamber of Commerce, Clyde Nelson, presented the Tourism Report. 2. Tourism Room Tax - SL304 for 2023 - The room tax report was included in the packet. XVII. Place Committee Reports on File 1. Consider placing the following reports on file: Committee of the Whole, Enrichment Center, Health & Safety, Festival Grounds, Library Board, Marketing & Communications, Personnel & Finance, Redevelopment Authority, Transit Commission, Board of Public Works, and Parks and Recreation Commission. - Alderperson Meyer motioned to place the committee reports on file. Alderperson Rick seconded and the motion passed XVIII. Ordinances XIX. An Ordinance Amending Chapter 26, Article V, Section 26-136 Purchase or possession of tobacco products. The Health & Safety Committee recommends approval. - City Attorney Hayden read the Ordinance. Alderperson Caylor motioned to suspend the rules and give the second and third readings by title only. Alderperson Rick seconded and the motion carried. City Attorney Hayden gave the Ordinance the second and third readings by title only. Alderperson Meyer motioned to adopt the Ordinance. Alderperson Lupton seconded and the motion carried on an 8/0 roll call vote. XX. Mayor's Appointments 1. Jim Weix to the Central Wisconsin Economic Development Board replacing Adam Rekau - Alderperson Meyer motioned to approve. Alderperson Rick seconded and the motion passed. Alderperson Weix abstained. XXI. Mayor's Communications Mayor Hass read the following communications: • I want to congratulate and welcome the Alderpersons elected to the Council, Andrew Caylor, Robert Lass, and Rebecca Rutkowski. I want to thank the outgoing aldermen, Paul Russell, who has been the Council President, Alderman Dick Lupton, and Alderman Steve Sabatke for their years of service to the city. • The Council will meet again on April 16 at 6:00 pm for a swearing-in ceremony and a re-organizational meeting where committee assignments will be given. • April 19th is the Concertina Fest at Les and Jim's. • April 25, 26, and 27, the Merrill High School Theatre Jays are presenting the musical Matilda. Please call 536-4594 for information and tickets. • April 28th is the Raise Your Voice walk at the MARC • This week is National Library Week. There will be activities all week. Please stop in and check out the TB Scott Library and all it has to offer. • May 18th is the City-wide garage sale and the Food Truck-a-palooza event at the Festival Grounds. • Please stop into the Enrichment Center and check out all the activities. We are lucky to have the Enrichment Center and the Library in our community. • May 3rd is the Council Orientation at 9:00 am. XXI. Adjournment Alderperson Meyer motioned to Adjourn. Alderperson Rick seconded and the motion passed. The meeting was adjourned at 7:48 pm. The complete Ordinance is available on the City of Merrill website: https://www.ci.merrill.wi.us/ Minutes respectfully submitted by Lori L Anderson-Malm - City Clerk Published April 18, 2024 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals
DATE SIGNED: 04/01/2024 /S/HON. Robert R. Russell STATE OF WISCONSIN CIRCUIT COURT, LINCOLN COUNTY Notice and Order for Name Change Hearing Case No. 24-CV-47 IN THE MATTER OF THE NAME CHANGE OF Pandora Mayhem Hayley By (Petitioner) Pandora Mayhem Hayley NOTICE IS GIVEN: A petition was filed asking to change the name of the person listed above: From: Pandora Mayhem Hayley To: Vladimir Mayhem Hayley Birth Certificate: Pandora Mayhem Hayley IT IS ORDERED: This petition will be heard in the Circuit Court of Lincoln County, State of Wisconsin: Judge’s Name: Honorable Robert R. Russell Place: Lincoln County Courthouse-Br II 1110 E. Main St., Merrill, WI 54452 Date: 05/24/2024 Time: 2:30 PM If you require reasonable accommoda-tions due to a disability to participate in the court process, please call prior to the scheduled court date. Please note that the court does not provide transportation. IT IS FURTHER ORDERED: Notice of this hearing shall be given by publication as a Class 3 notice for three (3) weeks in a row prior to the date of the hearing in the Foto News a newspaper published in Lincoln County, State of Wisconsin. Published: April 11, 18 & 25, 2024 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals
DATE SIGNED: April 11, 2024 Electronically signed by Becky S. Byer Probate Registrar STATE OF WISCONSIN, CIRCUIT COURT, LINCOLN COUNTY Notice to Creditors (Informal Administration) Case No. 2024-lN-17 IN THE MATTER OF THE ESTATE OF LINDA L. HENRICHS PLEASE TAKE NOTICE: 1. An application for informal administration was filed. 2. The decedent, with date of birth May 10, 1939 and date of death March 10, 2024, was domiciled in Lincoln County, State of Wisconsin, with a mailing address of 407 Cottage St, Merrill, WI 54452. 3. All interested persons waived notice. 4. The deadline for filing a claim against the decedent's estate is July 26, 2024. 5. A claim may be filed at the Lincoln County Courthouse, Merrill, Wisconsin, Probate Office. Craig J. Nienow N5041 County Road JJ lrma, Wl 54442 Telephone 71 5-536-7185 Bar Number 01015178 Published 4/18/24, 4/25/24 & 5/2/24 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals
DATE SIGNED: April 8, 2024 Electronically signed by Judge Troy L. Nielsen Circuit Court Judge STATE OF WISCONSIN, CIRCUIT COURT, WAUPACA COUNTY IN THE MATTER OF THE ESTATE OF ROGER DAVID STEINBACH DOD: 08/07/2023 Order Setting Time to Hear Petition for Administration and Deadline for Filing Claims (Formal Administration) Case No. 2023PR99 A Petition for Formal Administration was filed. THE COURT FINDS: The decedent, with date of birth 11/18/1958 and date of death 08/07/2023 was domiciled in Waupaca County, State of Wisconsin , with a mailing address of 208 W Sumner St, Weyauwega, WI 54983. THE COURT ORDERS: 1. The Petition be heard at the Waupaca County Courthouse, 811 Harding St, Waupaca, Wisconsin, Room Branch I, before Circuit Court Judge/Circuit Court Commissioner Hon. Troy Nielsen, on 05/03/2024 at11:00 a.m.. You do not need to appear unless you object. The petition may be granted if there is no objection. 2. The deadline for filing a claim against the decedent’s estate is [Date] July 9, 2024 . 3. A claim may be filed at the Waupaca County Courthouse, 811 Harding St, Waupaca , Wisconsin, Room 3054 / Probate Office. 4. Heirship will be determined at the hearing on petition for final judgment. 5. Publication of this notice is notice to any persons whose names or addresses are unknown. If you require reasonable accommodations due to a disability to participate in the court process, please call (715) 258-6429 prior to the scheduled court date. Please note that the court does not provide transportation. Form completed by: Matthew J. Linn PO Box 5 New London, WI 54961 Telephone Number (920) 982-4450 Bar Number 1066187 Publish April 11, 18 & 25, 2024 WNAXLP
You must Register or Login before you can email ad listings
Listed: Wed Apr 17th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals
Green Bay WNAXLP NOTICE The “Official City of Green Bay Newspaper Bid” IFB #2024-17 is available by e-mailing PurchasingAg@ greenbaywi.gov . Sealed bids will be opened Tuesday, April 23, 2024, at 2pm. Publish 04.05.24 & 04.12.24 WNAXLP
You must Register or Login before you can email ad listings
Listed: Wed Apr 10th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals
Green Bay WNAXLP NOTICE TO CONTROL NOXIOUS WEEDS NOTICE IS HEREBY GIVEN to each person who owns, occupies, or controls lands in the City of Green Bay, Brown County, Wisconsin, to destroy all noxious weeds on said lands before the plants mature to the bloom or flower stage. The following are noxious weeds: Canada thistle, leafy spurge, field bindweed, purple loosestrife or hybrids thereof, multiflora rose, and any other weed the Common Council of the City of Green Bay or the Brown County Board of Supervisors by ordinance or resolution declares to be noxious within its boundaries. In addition to the above noxious weeds, all plants out of place and considered detrimental to the City must be controlled on all lands. Weeds shall be controlled at such times and in such manner as will effectively prevent such plants from maturing to the bloom or flower stage, as set forth in Wis. Stat. § 66.0407. ___________________ Eric Genrich, Mayor City of Green Bay Publish 04.19.24 & 04.26.24 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals
Green Bay WNAXLP STATE OF WISCONSIN, CIRCUIT COURT, BROWN COUNTY ---------------------------------------- Plaintiff(s): Lebakkens Inc Of WI DBA Lebakkens Rent to Own 318 N. Military Avenue Green Bay, WI 54303 -vs- Defendant(s): Laquita S. Russ 718 Bond Street Green Bay, WI 54303 Publication Summons and Notice (Small Claims) Case No. 2024SC001557 If you require reasonable accommodations due to a disability to participate in the court process, please call 920-448-4155 prior to the scheduled court date. Please note that the court does not provide transportation. ---------------------------------------- Publication Summons and Notice of Filing TO THE PERSON(S) NAMED ABOVE AS DEFENDANT(S): You are being sued by the person(s) named above as Plaintiff(s). A copy of the claim has been sent to you at your address as stated in the caption above. The lawsuit will be heard in the following small claims court: Brown County Courthouse Telephone Number of clerk of court: 920-448-4155 Courtroom/Room Number: Courtroom B Address: 100 S. Jefferson Street Green Bay, WI 54301 on the following date and time: Date: 4/26/2024 Time: 1:15 p.m. If you do not attend the hearing, the court may enter a judgment against you in favor of the person(s) suing you. A copy of the claim has been sent to you at your address as stated in the caption above. A judgment may be enforced as provided by law. A judgment awarding money may become a lien against any real estate (property) you own now or in the future, and may also be enforced by garnishment or seizure of property. You may have the option to Answer without appearing in court on the court date by filing a written Answer with the clerk of court before the court date. You must send a copy of your Answer to the Plaintiff(s) named above at their address. You may contact the clerk of court at the telephone number above to determine if there are other methods to answer a Small Claims complaint in that county. Plaintiff Jess Guhl Date 04/08/2024 Publish 04.12.24 & 04.19.24 WNAXLP
You must Register or Login before you can email ad listings
Listed: Wed Apr 17th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals
Hobart WNAXLP Oneida Wetland Mitigation Site Invasive Species Control Robert E. Lee & Associates, Inc. has been contracted by the Wisconsin Department of Transportation (WisDOT) to spot treat 30 acres of invasive species (common reed (Phragmites australis), reed canary grass (Phalaris arundinacea), cattail (Typha spp), and purple loosestrife (Lythrum salicaria)) within the Oneida Wetland Mitigation Site (74 acres) located on the northwest side of the Village of Hobart. Work will begin in May and will conclude by October 31, 2024. All invasive species will be treated with an aquatic approved herbicide and follow guidelines provided by WisDOT, in order to reduce impacts to native plants and wildlife within the property. Herbicide treatments will be conducted by a combination of foliar spraying with a backpack sprayer or ATV tank sprayer, cutting stems and applying herbicide to the cut surface and hand wicking. Any request for a public meeting must be made within five days after this notice is published. The request must address the topics to be discussed at the meeting, including problems and alternatives, and must be sent in writing to the Wisconsin Department of Natural Resources, 2984 Shawano Avenue, Green Bay, WI, 54313 with attention to Claire Hetzel. This public notice is required by Chapter 107, Wisconsin Administrative Code. Publish 04.19.24 WNAXLP
You must Register or Login before you can email ad listings
Listed: Thu Apr 18th
classifiedsMMC.com
Legal Legals
classifiedsMMC.com
Legal Legals